Decisions to Withhold Certification § 9.5.1 The Architect may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner, if in the Architect’s opinion the representations to the Owner required by Section 9.4.2 cannot be made. If the Architect is unable to certify payment in the amount of the Application, the Architect will notify the Contractor and Owner as provided in Section 9.4.1. If the Contractor and Architect cannot agree on a revised amount, the Architect will promptly issue a Certificate for Payment for the amount for which the Architect is able to make such representations to the Owner. The Architect may also withhold a Certificate for Payment or, because of subsequently discovered evidence, may nullify the whole or a part of a Certificate for Payment previously issued, to such extent as may be necessary in the Architect’s opinion to protect the Owner from loss for which the Contractor is responsible, including loss resulting from acts and omissions described in Section 3.3.2, because of .1 defective Work not remedied;
Notices; Standards for Decisions and Determinations The Administrative Agent will promptly notify the Borrower and the Lenders of (A) the implementation of any Benchmark Replacement and (B) the effectiveness of any Conforming Changes. For the avoidance of doubt, any notice required to be delivered by the Administrative Agent as set forth in this Section 12.01(c) may be provided, at the option of the Administrative Agent (in its sole discretion), in one or more notices and may be delivered together with, or as part of any amendment which implements any Benchmark Replacement or Conforming Changes. Any determination, decision or election that may be made by the Administrative Agent or, if applicable, any Lender (or group of Lenders) pursuant to this Section 12.01(c), including any determination with respect to a tenor, rate or adjustment or of the occurrence or non-occurrence of an event, circumstance or date and any decision to take or refrain from taking any action, will be conclusive and binding absent manifest error and may be made in its or their sole discretion and without consent from any other party hereto, except, in each case, as expressly required pursuant to this Section 12.01(c).
Procedure for Notification and Defense of Claim (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request therefor specifying the basis for the claim, the amounts for which Indemnitee is seeking payment under this Agreement, and all documentation related thereto as reasonably requested by the Company.
(b) In the event that the Company shall be obligated hereunder to provide indemnification for or make any advancement of Expenses with respect to any Proceeding, the Company shall be entitled to assume the defense of such Proceeding, or any claim, issue or matter therein, with counsel approved by Indemnitee (which approval shall not be unreasonably withheld or delayed) upon the delivery to Indemnitee of written notice of the Company’s election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee under this Agreement for any fees or expenses of separate counsel subsequently employed by or on behalf of Indemnitee with respect to the same Proceeding; provided that (i) Indemnitee shall have the right to employ separate counsel in any such Proceeding at Indemnitee’s expense and (ii) if (A) the employment of separate counsel by Indemnitee has been previously authorized by the Company, (B) Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and Indemnitee in the conduct of such defense, or (C) the Company shall not continue to retain such counsel to defend such Proceeding, then the fees and expenses actually and reasonably incurred by Indemnitee with respect to his or her separate counsel shall be Expenses hereunder.
(c) In the event that the Company does not assume the defense in a Proceeding pursuant to paragraph (b) above, then the Company will be entitled to participate in the Proceeding at its own expense.
(d) The Company shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any Proceeding effected without its prior written consent (which consent shall not be unreasonably withheld or delayed). The Company shall not, without the prior written consent of Indemnitee (which consent shall not be unreasonably withheld or delayed), enter into any settlement which (i) includes an admission of fault of Indemnitee, any non-monetary remedy imposed on Indemnitee or any monetary damages for which Indemnitee is not wholly and actually indemnified hereunder or (ii) with respect to any Proceeding with respect to which Indemnitee may be or is made a party or may be otherwise entitled to seek indemnification hereunder, does not include the full release of Indemnitee from all liability in respect of such Proceeding.
Purpose; Incorporation by Reference of Auction Procedures and Settlement Procedures (a) The Statement for each series of MuniPreferred will provide that the Applicable Rate for such series for each Subsequent Rate Period thereof shall, except under certain conditions, be the rate per annum that a bank or trust company appointed by the Fund advises results from implementation of the Auction Procedures for such series. The Board of Directors or Board of Trustees, as the case may be, of the Fund has adopted a resolution appointing the Auction Agent as auction agent for purposes of the Auction Procedures for each series of MuniPreferred. The Auction Agent accepts such appointment and agrees to follow the procedures set forth in this Section 2 and the Auction Procedures for the purpose of determining the Applicable Rate for each series of MuniPreferred for each Subsequent Rate Period thereof for which the Applicable Rate is to be determined by an Auction. Each periodic implementation of such procedures is hereinafter referred to as an "Auction."
(b) All of the provisions contained in the Auction Procedures and the Settlement Procedures are incorporated herein by reference in their entirety and shall be deemed to be a part hereof to the same extent as if such provisions were fully set forth herein.
Selection and Payment of Appeal Panel In the event an Appellant delivers an Appeal Notice to the Appellee (together with proof of payment of the applicable bond) in compliance with the provisions of Paragraph 5.1 above, the Appeal will be heard by a three (3) person arbitration panel (the “Appeal Panel”).
(a) Within ten (10) calendar days after the Appeal Date, the Appellee shall select and submit to the Appellant the names of five (5) arbitrators that are designated as “neutrals” or qualified arbitrators by Utah ADR Services (xxxx://xxx.xxxxxxxxxxxxxxx.xxx) (such five (5) designated persons hereunder are referred to herein as the “Proposed Appeal Arbitrators”). For the avoidance of doubt, each Proposed Appeal Arbitrator must be qualified as a “neutral” with Utah ADR Services, and shall not be the arbitrator who rendered the Arbitration Award being appealed (the “Original Arbitrator”). Within five (5) calendar days after the Appellee has submitted to the Appellant the names of the Proposed Appeal Arbitrators, the Appellant must select, by written notice to the Appellee, three (3) of the Proposed Appeal Arbitrators to act as the members of the Appeal Panel. If the Appellant fails to select three (3) of the Proposed Appeal Arbitrators in writing within such 5-day period, then the Appellee may select such three (3) arbitrators from the Proposed Appeal Arbitrators by providing written notice of such selection to the Appellant.
(b) If the Appellee fails to submit to the Appellant the names of the Proposed Appeal Arbitrators within ten (10) calendar days after the Appeal Date pursuant to subparagraph (a) above, then the Appellant may at any time prior to the Appellee so designating the Proposed Appeal Arbitrators, identify the names of five (5) arbitrators that are designated as “neutrals” or qualified arbitrators by Utah ADR Service (none of whom may be the Original Arbitrator) by written notice to the Appellee. The Appellee may then, within five (5) calendar days after the Appellant has submitted notice of its selected arbitrators to the Appellee, select, by written notice to the Appellant, three (3) of such selected arbitrators to serve on the Appeal Panel. If the Appellee fails to select in writing within such 5-day period three (3) of the arbitrators selected by the Appellant to serve as the members of the Appeal Panel, then the Appellant may select the three (3) members of the Appeal Panel from the Appellant’s list of five (5) arbitrators by providing written notice of such selection to the Appellee.
(c) If a selected Proposed Appeal Arbitrator declines or is otherwise unable to serve, then the party that selected such Proposed Appeal Arbitrator may select one (1) of the other five (5) designated Proposed Appeal Arbitrators within three (3) calendar days of the date a chosen Proposed Appeal Arbitrator declines or notifies the parties he or she is unable to serve as an arbitrator. If at least three (3) of the five (5) designated Proposed Appeal Arbitrators decline or are otherwise unable to serve, then the Proposed Appeal Arbitrator selection process shall begin again in accordance with this Paragraph 5.2; provided, however, that any Proposed Appeal Arbitrators who have already agreed to serve shall remain on the Appeal Panel.
(d) The date that all three (3) Proposed Appeal Arbitrators selected pursuant to this Paragraph 5.2 agree in writing (including via email) delivered to both the Appellant and the Appellee to serve as members of the Appeal Panel hereunder is referred to herein as the “Appeal Commencement Date”. No later than five (5) calendar days after the Appeal Commencement Date, the Appellee shall designate in writing (including via email) to the Appellant and the Appeal Panel the name of one (1) of the three (3) members of the Appeal Panel to serve as the lead arbitrator in the Appeal proceedings. Each member of the Appeal Panel shall be deemed an arbitrator for purposes of these Arbitration Provisions and the Arbitration Act, provided that, in conducting the Appeal, the Appeal Panel may only act or make determinations upon the approval or vote of no less than the majority vote of its members, as announced or communicated by the lead arbitrator on the Appeal Panel. If an arbitrator on the Appeal Panel ceases or is unable to act during the Appeal proceedings, a replacement arbitrator shall be chosen in accordance with Paragraph 5.2 above to continue the Appeal as a member of the Appeal Panel. If Utah ADR Services ceases to exist or to provide a list of neutrals, then the arbitrators for the Appeal Panel shall be selected under the then prevailing rules of the American Arbitration Association.
Provide Data In Compliance With State and Federal Law LEA shall provide data for the purposes of the Service Agreement in compliance with FERPA, COPPA, PPRA, Texas Education Code Chapter 32, and all other Texas privacy statutes cited in this DPA as these laws and regulations apply to the contracted services. The LEA shall not be required to provide Data in violation of applicable laws. Operator may not require LEA or users to waive rights under applicable laws in connection with use of the Services.
Procedures for Notification and Defense of Claim (a) Indemnitee shall notify the Company in writing of any matter with respect to which Indemnitee intends to seek indemnification or advancement of Expenses as soon as reasonably practicable following the receipt by Indemnitee of notice thereof. The written notification to the Company shall include, in reasonable detail, a description of the nature of the Proceeding and the facts underlying the Proceeding. The failure by Indemnitee to notify the Company will not relieve the Company from any liability which it may have to Indemnitee hereunder or otherwise than under this Agreement, and any delay in so notifying the Company shall not constitute a waiver by Indemnitee of any rights, except to the extent that such failure or delay materially prejudices the Company.
(b) If, at the time of the receipt of a notice of a Proceeding pursuant to the terms hereof, the Company has directors’ and officers’ liability insurance in effect that may be applicable to the Proceeding, the Company shall give prompt notice of the commencement of the Proceeding to the insurers in accordance with the procedures set forth in the applicable policies. The Company shall thereafter take all commercially-reasonable action to cause such insurers to pay, on behalf of Indemnitee, all amounts payable as a result of such Proceeding in accordance with the terms of such policies.
(c) In the event the Company may be obligated to make any indemnity in connection with a Proceeding, the Company shall be entitled to assume the defense of such Proceeding with counsel approved by Indemnitee, which approval shall not be unreasonably withheld, conditioned or delayed, upon the delivery to Indemnitee of written notice of its election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee for any fees or expenses of counsel subsequently incurred by Indemnitee with respect to the same Proceeding. Notwithstanding the Company’s assumption of the defense of any such Proceeding, the Company shall be obligated to pay the fees and expenses of Indemnitee’s separate counsel to the extent (i) the employment of separate counsel by Indemnitee is authorized by the Company, (ii) counsel for the Company or Indemnitee shall have reasonably concluded that there is a conflict of interest between the Company and Indemnitee in the conduct of any such defense such that Indemnitee needs to be separately represented, (iii) the Company is not financially or legally able to perform its indemnification obligations or (iv) the Company shall not have retained, or shall not continue to retain, counsel to defend such Proceeding. The Company shall have the right to conduct such defense as it sees fit in its sole discretion. Regardless of any provision in this Agreement, Indemnitee shall have the right to employ counsel in any Proceeding at Indemnitee’s personal expense. The Company shall not be entitled, without the consent of Indemnitee, to assume the defense of any claim brought by or in the right of the Company.
(d) Indemnitee shall give the Company such information and cooperation in connection with the Proceeding as may be reasonably appropriate.
(e) The Company shall not be liable to indemnify Indemnitee for any settlement of any Proceeding (or any part thereof) without the Company’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.
(f) The Company shall not settle any Proceeding (or any part thereof) in a manner that imposes any penalty or liability on Indemnitee without Indemnitee’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.
Amendment Procedure (a) Except as provided in subsection (b) of this Section 11.3, this Declaration may be amended, after a majority of the Trustees have approved a resolution therefor, by the affirmative vote required by Section 10.4 of this Declaration. The Trustees also may amend this Declaration without any vote of Shareholders of any class or series to divide the Shares of the Trust into one or more classes or additional classes, or one or more series of any such class or classes, to determine the rights, powers, preferences, limitations and restrictions of any class or series of Shares, to change the name of the Trust or any class or series of Shares, to make any change that does not adversely affect the relative rights or preferences of any Shareholder, as they may deem necessary, or to conform this Declaration to the requirements of the 1940 Act or any other applicable federal laws or regulations including pursuant to Section 6.2 or the requirements of the regulated investment company provisions of the Code, but the Trustees shall not be liable for failing to do so.
(b) No amendment may be made to Section 2.1, Section 2.2, Section 2.3, Section 3.9, Section 5.1, Section 5.2, Section 11.2(a), this Section 11.3, Section 11.4, Section 11.6 or Section 11.7 of this Declaration and no amendment may be made to this Declaration which would change any rights with respect to any Shares of the Trust by reducing the amount payable thereon upon liquidation of the Trust or by diminishing or eliminating any voting rights pertaining thereto (except that this provision shall not limit the ability of the Trustees to authorize, and to cause the Trust to issue, other securities pursuant to Section 6.2), except after a majority of the Trustees have approved a resolution therefor, by the affirmative vote of the holders of not less than seventy-five percent (75%) of the Shares of each affected class or series outstanding, voting as separate classes or series, unless such amendment has been approved by eighty percent (80%) of the Trustees, in which case approval by a Majority Shareholder Vote shall be required. Nothing contained in this Declaration shall permit the amendment of this Declaration to impair the exemption from personal liability of the Shareholders, Trustees, officers, employees and agents of the Trust or to permit assessments upon Shareholders.
(c) An amendment duly adopted by the requisite vote of the Board of Trustees and, if required, the Shareholders as aforesaid, shall become effective at the time of such adoption or at such other time as may be designated by the Board of Trustees or Shareholders, as the case may be. A certification in recordable form signed by a majority of the Trustees setting forth an amendment and reciting that it was duly adopted by the Trustees and, if required, the Shareholders as aforesaid, or a copy of the Declaration, as amended, in recordable form, and executed by a majority of the Trustees, shall be conclusive evidence of such amendment when lodged among the records of the Trust or at such other time designated by the Board. Notwithstanding any other provision hereof, until such time as a Registration Statement under the Securities Act of 1933, as amended, covering the first public offering of Shares of the Trust shall have become effective, this Declaration may be terminated or amended in any respect by the affirmative vote of a majority of the Trustees or by an instrument signed by a majority of the Trustees.
Automated decisions For purposes hereof “automated decision” shall mean a decision by the data exporter or the data importer which produces legal effects concerning a data subject or significantly affects a data subject and which is based solely on automated processing of personal data intended to evaluate certain personal aspects relating to him, such as his performance at work, creditworthiness, reliability, conduct, etc. The data importer shall not make any automated decisions concerning data subjects, except when:
a) i. such decisions are made by the data importer in entering into or performing a contract with the data subject, and
Amendment Procedures Amendments to this Agreement may be proposed only by the General Partner. To the fullest extent permitted by law, the General Partner shall have no duty or obligation to propose or approve any amendment to this Agreement and may decline to do so free of any duty or obligation whatsoever to the Partnership, any Limited Partner or any other Person bound by this Agreement, and, in declining to propose or approve an amendment to this Agreement, to the fullest extent permitted by law shall not be required to act in good faith or pursuant to any other standard imposed by this Agreement, any Group Member Agreement, any other agreement contemplated hereby or under the Delaware Act or any other law, rule or regulation or at equity, and the General Partner in determining whether to propose or approve any amendment to this Agreement shall be permitted to do so in its sole and absolute discretion. An amendment to this Agreement shall be effective upon its approval by the General Partner and, except as otherwise provided by Section 13.1 or Section 13.3, the holders of a Unit Majority, unless a greater or different percentage of Outstanding Units is required under this Agreement. Each proposed amendment that requires the approval of the holders of a specified percentage of Outstanding Units shall be set forth in a writing that contains the text of the proposed amendment. If such an amendment is proposed, the General Partner shall seek the written approval of the requisite percentage of Outstanding Units or call a meeting of the Unitholders to consider and vote on such proposed amendment. The General Partner shall notify all Record Holders upon final adoption of any amendments. The General Partner shall be deemed to have notified all Record Holders as required by this Section 13.2 if it has posted or made accessible such amendment through the Partnership’s or the Commission’s website.
