Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the District as a separate demand by the Contractor for: (1) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by, or on behalf of, the Contractor pursuant to the Contract and payment for which is not otherwise expressly provided for or to which the Contractor is not otherwise entitled to; or (3) an amount of payment disputed by the District. If the Claim is for damages associated with a DSA Stop Work Order, the Contractor shall not be entitled to a request for Compensation, but shall be entitled to utilize Governmental Delay Float (See Article 9.2.
Definition of Claim. 25.3.1 Pursuant to Public Contract Code section 9204, the term “Claim” means a separate demand by Developer sent by registered mail or certified mail with return receipt requested, for one or more of the following:
25.3.1.1 A time extension, including without limitation, for relief of damages or penalties for delay assessed by the District under the Contract;
25.3.1.2 Payment by the District of money or damages arising from work done by, or on behalf of, Developer pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Developer is not otherwise entitled to; or
25.3.1.3 An amount of payment disputed by the District.
Definition of Claim. 1Pursuant to Public Contract Code section 9204, the term “Claim” means a separate demand by Developer sent by registered mail or certified mail with return receipt requested, for one or more of the following:
Definition of Claim. As used in this article, the term “Claim” shall mean all claims, disputes and other controversies between one Party and another Party, regardless of how the same may have arisen or on what it might be based, excepting only those matters identified as exclusions in this Section below. Without limiting the generality of the foregoing, “Claim” shall include all claims, disputes or controversies relating to or arising out of, in whole or in part, any of the following: (a) any Agreement for Sale and Purchase between Declarant and any Owner; (b) the Property or the Unit (as defined in any such Agreement); (c) the purchase of the Property or the Unit; (d) the interpretation, application or enforcement of any of the Association Documents; (e) the soils of any property that lie within the Community or the presence of radon and/or mold within any Unit or other areas within the Community; (f) land development, design, construction and/or alteration of any of the improvements within the Community and/or any alleged defect therein; (g) any rights, obligations or duties of any Party under any of the Association Documents or any warranty, whether express, implied or limited, owed by a Party; (h) any limited warranty agreement between Declarant and any Owner and/or the Association; or (i) any breach of any of the foregoing referenced documents. Notwithstanding the foregoing, the following will not be considered “Claims” unless all parties to the matter otherwise agree to submit the matter to the Procedures set forth in this Article: (i) any suit by the Association to collect assessments or other amounts due from any Owner, (ii) any suit or other action by the Association or Declarant to act under or enforce any provisions of this Declaration relating to additions or alteration of improvements by Owners and/or any restrictive covenants or obligations of this Declaration, including any suit to obtain a temporary restraining order or injunction (or equivalent emergency equitable relief) or such other ancillary relief as the court may deem necessary, and (iii) any suit between Owners, which does not include Declarant or the Association as a party.
Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the Owner as a separate demand by the Contractor for: (1) a time extension including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract; (2) payment by the District of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract and payment for which is not otherwise expressly provided for or to which the Contractor is not otherwise entitled to; or (3) an amount of payment disputed by the Owner.
Definition of Claim. 13.2.1 Pursuant to Public Contract Code section 9204, the term “Claim” means a separate demand by the DBE sent by registered mail or certified mail with return receipt requested, for one or more of the following:
13.2.2 A time extension, including without limitation, for relief of damages or penalties for delay assessed by the District under the Contract;
13.2.2.1 Payment by the District of money or damages arising from work done by, or on behalf of, the DBE pursuant to the Contract and payment of which is not otherwise expressly provided for or to which DBE is not otherwise entitled to; or
13.2.2.2 An amount of payment disputed by the District.
Definition of Claim. As used herein "claim" means a written demand or assertion by one of the parties seeking, as a legal right, the payment of money, adjustment or interpretation of the Agreement terms, or other relief, arising under or relating to this Agreement. A voucher, invoice, or request for payment that is not in dispute when submitted is not a claim under this clause. However, where the submission is subsequently not acted upon in a reasonable time, or disputed either as to liability or amount, it may be converted to a claim for the purpose of this clause. A claim by the Contractor shall be made in writing and submitted to the City. When a controversy cannot be resolved by mutual agreement, the Contractor shall submit a written request for final decision to the City. The written request shall set forth all the facts surrounding the controversy.
Definition of Claim. A “Claim” is where a Dispute between the parties rises to the level where backup documentation is assembled and provided to the District as a separate demand by the Contractor for (1) time extension, (2) payment of money or damages arising from Work done by or on behalf of the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (3) and amount the payment of which is disputed by the District. (If the Claim is for damages associated with a DSA Stop Work Order, the Contractor shall not be entitled to a request for Compensation, but shall be entitled to utilize Governmental Delay Float (See Article 9.2.1.))
Definition of Claim. A claim by Contractor shall be made in writing and submitted to Contract Administrator. When a controversy cannot be resolved by mutual agreement, Contractor shall submit a written request for final decision to Contract Administrator. The written request shall set forth all the facts surrounding the controversy.
Definition of Claim. As used in this Article XI, “claims” shall include claims, demands, causes of action, liabilities, damages, penalties and judgments of any kind or character arising out of or in any way connected with the Subject Property and all costs and fees in connection therewith.
