Delay of Work. Any delay in the performance of this Contract due to strikes, lockouts, fires, or other unavoidable casualties beyond the control of the Contractor and not caused by any wrongful act or negligence of the Contractor shall entitle the Contractor to an extension of time equal to the delay so caused. The Contractor shall notify the Owner in writing specifying such cause within twenty-four (24) hours after its occurrence. In the event such delay is caused by strikes, lockouts, or inability to obtain workmen for any other cause, the Owner shall have the right but shall not be obligated to complete the work on the same basis as is provided for in Section 13 below (Contract Violations).

Delay of Work. If the performance of all or any part of the work is delayed or interrupted by an act of the Contracting Officer in the administration of this Contract, which act is not expressly or impliedly authorized by this Contract, or by his failure to act within the time specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this Contract caused by such delay or interruption and the Contract modified in writing accordingly. Adjustment shall be made also in the delivery or performance dates and any other contractual provision affected by such delay or interruption. However, no adjustment shall be made under this article for any delay or interruption (i) to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor; or (ii) for which an adjustment is provided or excluded under any other provision of this Contract. No claim under this clause shall be allowed: (a) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and (b) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of such delay or interruption, but not later than the date of final payment under the Contract.

Delay of Work a. If the performance of all or any part of the work is delayed or interrupted by an act of the Contracting Officer in the administration of this Contract, which act is not expressly or impliedly authorized by this Contract, or by his failure to act within the time specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this Contract caused by such delay or interruption and the contract modified in writing accordingly. Adjustment shall be made also in the delivery or performance dates and any other contractual provision affected by such delay or interruption. However, no adjustment shall be made under this article for any delay or interruption

Delay of Work. 29.1. No adjustment shall be made under this General Condition for any delay or interruption to the extent that performance would have been delayed or interrupted by any cause, including the fault or negligence of the CONSULTANT, or for which an adjustment is provided or excluded under any other provision of this Contract.

Delay of Work. 24.1 If the performance of all or any part of the work of this Contract is delayed or interrupted (a) by an act of the Chief Procurement Officer in the administration of this Contract that is not explicitly or implicitly authorized by this Contract, or (b) by a failure of the Chief Procurement Officer to act within the time specified in this Contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this Contract caused by the delay or interruption and the Contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other Contractual provision affected by the delay or interruption.

Related to Delay of Work

OF WORK The normal hours of work for an employee are not a guarantee of work per day or per week, or a guarantee of days of work per week. The normal hours of work shall be seven and one-half (7%) hours per day, and seventy-five (75) hours in any period. The normal daily tour shall consist of seven and one-half hours, exclusive of a one-half hour unpaid meal period. Employees shall be entitled to a fifteen (15) minute paid break during each half of the normal daily tour, at a time designated by the Employer. Employees required for reporting purposes shall remain at work for a period of up to fifteen (15) minutes which shall be unpaid. Should the reporting time extend beyond fifteen ( I 5) minutes however, the entire period shall be considered for the purposes of payment. Requests for change in posted work schedules must be submitted in writing and by the employee willing to exchange days off or shifts and are subject to the discretion of the Administrator or her designate. In any event, it is understood that such a change initiated by the employee and approved by the Employer shall not result in overtime compensation or payment or any other claims on the Employer by an employee under the terms of this t Where there is a change to Daylight Savings from Standard Time or vice-versa, an employee who is scheduled and works a full shift shall be paid for a seven and one-half (7.5) hour tour rather than the actual hours worked. The Employer will endeavour to accommodate requests by employees for specific days off and also requests for changes in posted time schedules once the schedule has been posted. Shift schedules shall be posted two (2) weeks in advance and shall cover a minimum of a four (4) week period. The following shall apply to full-time employees: During each pay period, two (2) consecutive days off will be scheduled. Schedules may provide for more than (5) consecutive days of work, but not more than seven (7) consecutive days of work without days off, as long as four (4) days off are scheduled in each fourteen (14) day period. Except as outlined below, meal time of one-half hour shall be scheduled away from the floor during the employee's shift whether day, evening or night. Where there is only one registered employee on duty, it is recognized that this is not possible. Should an employee be recalled to duty during meal time, additional time shall be provided later in the shift.
Xxxxx of Work The Contractor shall provide information technology (IT) independent verification and validation (IV&V) services to Customers in accordance with this Statement of Work (SOW). The Contractor shall provide the professional and technical staff necessary to perform the ((IT) IV&V services required by this Contract, and the staff shall have sufficient skill and experience to perform the services assigned to them. All of the (IT) IV&V services to be furnished by the Contractor under the Contract shall meet the professional standard and quality that prevail among IT professionals in the same discipline and of similar knowledge and skill engaged in related work under the same or similar circumstances. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required to perform the (IT) IV&V services.
Completion of Work Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order.
Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.
Cost of Work The Cost of Work will be adjusted and finalized as part of the Contract Sum in the GMP. The budget for the Cost of Work shall not exceed Five Million Three Hundred Six Thousand Eight Hundred Five and No/100 Dollars ($5,306,805.00).
Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.
Completion of Works Buildings will be considered complete on the issue of the City’s Certificate of Occupancy. Other structures will be considered complete on the issue of the Company’s engineers notification of the completion of construction, and by the City’s certification.
CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.
Cessation of Work Any one or all employees working in the immediate proximity when a fatal accident has occurred may without discrimination refrain from working the balance of the shift.
LAYOUT OF WORK The Contractor shall lay out its Work from base lines and benchmarks indicated on the Drawings, and shall be responsible for verification of all measurements in connection with the layout. The Contractor shall furnish all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the Work. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by Princeton University until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, Princeton University may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor. CLAUSE C15 NOISE

Delay of Work Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Delay of Work