DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES Sample Clauses

DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. 3.1 The Design Professional is the individual or legal entity identified in the Contract Documents and/or otherwise designated by the Owner who is retained by the Owner to design and/or oversee the Project. For purposes of this Contract only, the term also includes individuals employed by Northern Arizona University who render such services in connection with the Project. 3.2 The DP shall have the right, responsibility and authority to carry out the specific duties required of the DP, as described herein and in the Agreement(s) between the DP and the Owner, including any amendments thereto. Any such amendments shall be in writing and furnished to the Contractor. 3.3 The DP will visit the site as it is deemed by the DP or Owner to be appropriate in order to advise the Owner as to the quality and progress of the construction. The Contractor shall cooperate with the DP in all respects in this regard, including attending meetings as requested. 3.4 The Design Professional will be the initial interpreter of the intent and requirements of the Construction Documents. The Design Professional shall render written initial interpretations with reasonable promptness following a written request from the Owner or the Contractor in that regard. These initial interpretations shall be consistent with the intent of the Contract Documents. 3.5 The Design Professional will timely review and approve or take other appropriate action upon the Contractor’s submittals, such as Shop Drawings, Product Data and Samples, for conformance with the Construction Documents. Such action shall be taken with reasonable promptness as specified so as to cause no delay. The Design Professional’s approval of a specific item or component shall not indicate approval of an assembly of which the item is a component. 3.6 Following consultation with the Owner, the Design Professional will take appropriate action to facilitate issuance of amendments or change orders and may authorize minor changes in the Work as defined in Section 11.3. 3.7 The Design Professional and Owner will each have authority to reject any Work which does not conform to the Contract Documents and to require special inspection or testing but may take such action only after consultation with the other. However, neither the authority to act given to the Design Professional and the Owner under this subparagraph nor any decision made by them in good faith either to exercise or not exercise such authority shall give rise to any duty or r...
AutoNDA by SimpleDocs
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. 3.1 The Design Professional will be the initial interpreter of the intent and requirements of the Construction Documents. Following a written request from the Owner or CM@Risk, the Design Professional shall promptly provide a written interpretation of the intent or requirements of the Construction Documents. These initial interpretations shall be consistent with the intent of the Contract Documents. 3.2 The Design Professional will timely review and approve or take other appropriate action upon the CM@Risk’s submittals, such as shop drawings, product data and samples, to ensure conformance with the Construction Documents. Such action shall be taken with reasonable promptness as specified so as not to cause delay. The Design Professional’s approval of a specific item or component shall not indicate approval of an assembly of which the item is a component. 3.3 Following consultation with the Owner, the Design Professional will take appropriate action to facilitate issuance of amendments or change orders and may authorize minor changes in the Work as defined in Section 10.3. 3.4 The Design Professional and Owner will each have authority to reject any Work which does not conform to the Contract Documents and to require special inspection or testing, but may take such action only after consultation with the other. However, neither the authority to act given to the Design Professional and the Owner under this subparagraph nor any decision made by them in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility by them to the CM@Risk, any Subcontractor, any of their agents or employees, or any other person performing any of the Work. 3.5 Based on its observations of the Work and evaluation of applications for payment the Design Professional will have the responsibility to determine the amounts owed to the CM@Risk from time to time under and in accordance with Section 7 of these General Conditions and applicable law.
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. BASIC SERVICES Basic Services to be provided by Design Professional consist of the services described in this Article 2.
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. BASIC SERVICES
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. ADDITIONAL SERVICES Unless required to be performed as part of basic services, the services described in this Article 3 are additional services. These Additional Services shall be paid for by University, as provided in this Agreement, in addition to the compensation for Basic Services. Design Professional shall provide Additional Services only when and as authorized in a written Agreement Change Authorization signed by University. No Additional Services shall be compensable unless so authorized.
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES 

Related to DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require. (b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price. (c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work. (d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.

  • CONSULTANT’S RESPONSIBILITIES In addition to all other obligations contained herein, the Consultant agrees, warrants, and represents that: 6.1 The Consultant will furnish all material, equipment, labor and supplies in such quantities and of the proper quality to professionally and timely perform the Services, except as otherwise mutually agreed by the Parties; 6.2 The Consultant shall perform the Services with the professional skill and care ordinarily provided by competent consultants practicing in the same or similar locality and under the same or similar circumstances and professional license; 6.3 The Consultant will comply with the provisions of all federal, state, and local laws, regulations, ordinances, requirements and codes which are applicable to its performance of Services; 6.4 The Consultant is not and will not be bound by any agreement and has not assumed nor will assume any obligation which would, in any way, restrict its ability to perform the Services or be inconsistent with the Services; 6.5 In performing the Services, the Consultant will not use any third party’s confidential or propriety information, or infringe the rights of another party, nor will the Consultant disclose to the Authority, or bring onto the Authority’s premises, or induce the Authority to use any third party’s confidential or proprietary information; 6.6 The Consultant does not have the authority to act for the Authority, bind the Authority in any respect, or incur any debts or liabilities in the name of or on behalf of the Authority, except as otherwise expressly authorized in writing by the Authority; 6.7 Consultant is an independent contractor for the performance of his duties under this Contract. Accordingly, the Consultant shall be responsible for payment of all taxes including federal, state and local taxes arising out of the Consultant’s activities in accordance with this Contract. Consultant is responsible for payment of the compensation, including any withholding, Social Security, or other taxes on such compensation, of any subcontractors retained by Consultant, or Consultant's employees performing Services consistent with its status as an independent contractor and in compliance with all applicable laws and regulations; 6.8 Consultant has and hereby retains full control of any supervision over the Consultant’s obligations hereunder and over any persons employed or subcontracted by the Consultant for performing Services hereunder; 6.9 Consultant will in no way be considered an agent, partner, joint venturer, or employee of Authority at any time during the Term. Consultant will not undertake to commit Authority to any course of action in relation to a third party unless expressly requested and authorized to do so by the Authority in writing. 6.10 As of the Effective Date and at all times while providing Services hereunder, the Consultant shall possess and maintain in good standing any and all licenses or other authorizations and approvals necessary to perform the Services.

  • Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.

  • PROVIDER’S RESPONSIBILITIES A DBE prime may receive credit toward the DBE goal for work performed by his-her own forces and work subcontracted to DBEs. A DBE prime must make a good faith effort to meet the goals. In the event a DBE prime subcontracts to a non-DBE, that information must be reported to the Department. a. A Provider who cannot meet the contract goal, in whole or in part, shall document the “Good Faith Efforts” taken to obtain DBE participation. The following is a list of the types of actions that may be considered as good faith efforts. It is not intended to be a mandatory checklist, nor is it intended to be exclusive or exhaustive. Other factors or types of efforts may be relevant in appropriate cases. (1) Soliciting through all reasonable and available means the interest of all certified DBEs who have the capability to perform the work of the contract. The solicitation must be done within sufficient time to allow the DBEs to respond to it. Appropriate steps must be taken to follow up initial solicitations to determine, with certainty, if the DBEs are interested. (2) Selecting portions of the work to be performed by DBEs in order to increase the likelihood that the DBE goals will be achieved. This includes, where appropriate, breaking out contract work items into economically feasible units to facilitate DBE participation, even when the Provider might otherwise prefer to perform the work items with its own forces. (3) Providing interested DBEs with adequate information about the plans, specifications, and requirements of the contract in a timely manner to assist them in responding to a solicitation. (4) Negotiating in good faith with interested DBEs by making a portion of the work available to DBE subproviders and suppliers and selecting those portions of the work or material needs consistent with the available DBE subproviders and suppliers. (5) The ability or desire of the Provider to perform the work of a contract with its own organization does not relieve the Provider’s responsibility to make a good faith effort. Additional costs involved in finding and using DBEs is not in itself sufficient reason for a Provider’s failure to meet the contract DBE goal, as long as such costs are reasonable. Providers are not, however, required to accept higher quotes from DBEs if the price difference is excessive or unreasonable. (6) Not rejecting DBEs as being unqualified without sound reasons based on a thorough investigation of their capabilities. (7) Making efforts to assist interested DBEs in obtaining bonding, lines of credit, or insurance as required by the recipient or Provider. (8) Making efforts to assist interested DBEs in obtaining necessary equipment, supplies, materials or related assistance or services. (9) Effectively using the services of available minority/women community organizations; minority/women contractors’ groups; local, state, and Federal minority/women business assistance offices; and other organizations as allowed on a case-by-case basis to provide assistance in the recruitment and placement of DBEs. (10) If the Department’s Director of the Business Opportunity Programs Office determines that the Provider has failed to meet the good faith effort requirements, the Provider will be given an opportunity for reconsideration by the Director of the appropriate Division. NOTE: The Provider must not cause or allow subproviders to bid their services. b. The preceding information shall be submitted directly to the Chair of the Consultant Selection Team responsible for the project. c. The Provider shall make all reasonable efforts to honor commitments to DBE subproviders named in the commitment submitted under Section 2.c. of this attachment. Where the Provider terminates or removes a DBE subprovider named in the initial commitment, the Provider must demonstrate on a case-by-case basis to the satisfaction of the department that the originally designated DBE was not able or willing to perform. d. The Provider shall make a good faith effort to replace a DBE subprovider that is unable or unwilling to perform successfully with another DBE, to the extent needed to meet the contract goal. The Provider shall submit a completed Exhibit H-2 Form for the substitute firm(s). Any substitution of DBEs shall be subject to prior written approval by the Department. The Department may request a statement from the firm being replaced concerning its replacement prior to approving the substitution. e. The Provider shall designate a DBE liaison officer who will administer the DBE program and who will be responsible for maintenance of records of efforts and contacts made to subcontract with DBEs. f. Providers are encouraged to investigate the services offered by xxxxx owned and controlled by disadvantaged individuals and to make use of these banks where feasible.

  • Roles and Responsibilities 1. The Donor States shall make funds available in support of eligible programmes proposed by the Beneficiary State and agreed on by the Financial Mechanism Committee within the priority sectors listed in Article 3.1 of Protocol 38c and the programme areas listed in the Annex to Protocol 38c. The Donor States and the Beneficiary State shall cooperate on the preparation of concept notes defining the scope and planned results for each programme. 2. The Beneficiary State shall assure the full co-financing of programmes that benefit from support from the EEA Financial Mechanism 2014-2021 in accordance with Annex B and the programme agreements. 3. The Financial Mechanism Committee shall manage the EEA Financial Mechanism 2014-2021 and take decisions on the granting of financial assistance in accordance with the Regulation. 4. The Committee shall be assisted by the Financial Mechanism Office (hereinafter referred to as the “FMO”). The FMO shall be responsible for the day-to-day operations of the EEA Financial Mechanism 2014-2021 and shall serve as a contact point.

  • IRO Responsibilities The IRO shall: 1. perform each Claims Review in accordance with the specific requirements of the CIA;

  • Provider Responsibilities The Private Child-Caring Facility (PCC) (a.k.a., Provider) must comply with the following requirements:

  • Client Responsibilities You are responsible for (a) assessing each participants’ suitability for the Training, (b) enrollment in the appropriate course(s) and (c) your participants’ attendance at scheduled courses.

  • Vendor Responsibilities Note: NO EXCEPTIONS OR REVISIONS WILL BE CONSIDERED IN C-M, O-S, V-W. Indemnification

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!