Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Lease Termination Notwithstanding any other provisions in this Lease, this Lease will terminate and the Tenant must immediately vacate the Leased Premises upon:
(i) The date on which the Tenant is no longer enrolled as a student in a course of full-time study at the University of Toronto Mississauga, provided that the Tenant shall be deemed to be enrolled as a student in a course of full-time study to the last day of the summer recess immediately following the completion by the Tenant of a scholastic year of full-time study.
(ii) The Landlord and the Tenant agree that, once the Tenant ceases to be enrolled as a student in a course of full-time study at the University of Toronto Mississauga, the Tenant’s continued occupation of the Leased Premises constitutes a substantial interference with the Landlord’s lawful rights, privileges, and interests, and this is grounds for the Landlord to terminate the Lease.
(iii) The provisions of this subparagraph 7(k) are strictly for the benefit of the Landlord. The Landlord may, in its sole discretion, elect to waive any or all provision(s) of this subparagraph 7(k) and require the Tenant to remain in occupation of the Leased Premises to the end of the term of the Lease. Alternatively, if the Landlord (at its sole discretion) elects to waive any or all provision(s) of this subparagraph 7(k), the Landlord and the Tenant may mutually agree to change the term of the Lease to require or allow the Tenant to remain in occupation of the Leased Premises until a mutually agreed upon date prior to the end of the term of the Lease.
(iv) If either party has given notice to terminate this Lease pursuant to any provision herein, the Leased Premises may be shown to prospective Tenants between the hours of 8:00 am and 8:00 pm by the Landlord. Should the Tenant effectively deny the Landlord reasonable viewing rights.
(v) In the event that the Tenant is obliged to vacate the Leased Premises on or before a certain date, and the Landlord enters into a tenancy agreement with a third party to lease the Premises herein described for any period thereafter, and the Tenant fails to vacate the Leased Premises on or before the due date, thereby causing the Landlord to be liable to such third party, then the Tenant will indemnify the Landlord for all losses suffered thereby, including, without limiting the generality of the foregoing, all legal costs incurred by the Landlord, such legal costs to be computed on a full indemnity basis.
RIGHT OF LANDLORD TO PERFORM All covenants and agreements to be performed by Tenant under any of the terms of this Lease shall be performed by Tenant at Tenant's sole cost and expense and without any abatement of rent. If Tenant shall fail to pay any sum of money, other than rent, required to be paid by it hereunder or shall fail to perform any other act on its part to be performed hereunder, and such failure shall continue beyond any applicable cure period set forth in this Lease, Landlord may, but shall not be obligated to, without waiving or releasing Tenant from any obligations of Tenant, make any such payment or perform any such other act on Tenant's part to be made or performed as is in this Lease provided. All sums so paid by Landlord and all reasonable incidental costs, together with interest thereon at the rate of ten percent (10%) per annum from the date of such payment by Landlord, shall be payable to Landlord on demand and Tenant covenants to pay any such sums, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the nonpayment thereof by Tenant as in the case of default by Tenant in the payment of the rent.
Termination by Landlord If the Resident fails to adhere to the Community Standards and House Rules, or fails to perform and observe any of the terms or conditions of this Residence Agreement, the Landlord, at its option and in its sole discretion, may terminate the Term created by this Residence Agreement upon giving the Resident written notice of the Landlord’s intention to do so, to take effect within no less than forty-eight (48) hours from receipt of a Notice to Vacate from the Landlord. Notwithstanding the foregoing, a Resident may be immediately evicted from the Premises and Residence for reasons including but not limited to assault of any kind, any offence resulting in a criminal charge, any destruction of property, or if the Resident is deemed a safety concern for the community. The Resident is liable to pay all legal costs incurred by the Landlord in enforcing the provisions of this Residence Agreement including obtaining possession of the Premises.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Termination of the Lease The parties agree that the Management Agreement and the rights and benefits of Manager thereunder shall not be terminated or disturbed in any respect except in accordance with the terms of the Management Agreement, and not as a result of any termination of the Lease. Accordingly, if the Lease is terminated for any reason, including, without limitation, expiration of the term thereof or the "rejection" thereof following Bankruptcy
(a) shall recognize Manager's rights under the Management Agreement, (b) agrees that Manager shall not be named as a party in any eviction or other possessory action or proceeding, and that Manager shall not be disturbed in its right to manage the Inn pursuant to the Management Agreement, and (c) shall at the time of or prior to such Lease Termination either (i) elect not to take either of the actions described in clause (c)(ii) below, in which case all of "Lessee's" rights, benefits, privileges and obligations under the Management Agreement with respect to periods after the Lease Termination shall be assumed directly by Lessor, or (ii) cause an "Approved Lessee" (as defined below) to (x) succeed to and assume Lessee's rights and obligations under the Lease, the Management Agreement, and this Agreement, or (y) enter into a new lease with Lessor in substantially the same form as the Lease, and assume the rights and obligations of the Lessee under the Management Agreement and this Agreement, the intent being that the relationship between any successor Lessee, Lessor and Manager be under the same terms and conditions as the relationship between Lessee, Lessor and Manager hereunder and under the Management Agreement and the Lease. Any successor to Lessee under clause (c)(ii) above shall be subject to Manager's prior written approval, which approval shall not be withheld or delayed if such successor to Lessee is (i) a direct or indirect wholly-owned subsidiary of Lessor, (ii) a person or entity to whom a Sale of the Inn is permitted under Section 10.02.A. of the Management Agreement, or (iii) a person or entity who otherwise is approved by Manager in its sole discretion (an "Approved Lessee").
Non-Renewal Termination If the Agreement expires as set forth in Section 6(g) [Non-Renewal Termination], then, subject to Section 22 [Compliance with Section 409A], in addition to all salary, annual bonuses, expense reimbursements, benefits and accrued vacation days earned by the Executive pursuant to Section 4 through the date of the Executive’s termination of employment, the Executive shall be entitled to the compensation set forth in Sections 8(d)(i) through (v), provided that within sixty days following the Executive’s termination of employment (i) the Executive has executed and delivered the Release to the Company, and (ii) the Release has become irrevocable:
