Landlord Caused Delays Sample Clauses

Landlord Caused Delays. The Lease Commencement Date shall occur as provided in Section 2.1 of this Lease and Section 3.2 of the Summary; provided, however, that the Lease Commencement Date shall be extended on a day-for-day basis by the number of actual days of delay of the “Substantial Completion of the Improvements,” as that term is defined in Section 5.3 below, to the extent caused by a Landlord Caused Delay. As used in this Tenant Work Letter, “Landlord Caused Delay” shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to timely approve or disapprove any Construction Drawings; (ii) material and unreasonable interference by Landlord, its agents, employees or contractors with the Substantial Completion of the Improvements and which objectively preclude or delay the construction of Improvements in the Building by any person, which interference relates to access by Xxxxxx, or Xxxxxx’s Agents to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; (iii) delays due to the acts or failures to act of Landlord, its agents, employees or contractors including without limitation any such acts or failures to act with respect to payment of the Improvement Allowance; and (iv) delays due to Landlord’s non-delivery of the Premises in a condition which allows Tenant to construct the Improvements without material delays and/or any lack of reasonably sufficient access thereto to allow Tenant to construct the Improvements on a timely basis.
Sample 1Sample 2See All (13)
AutoNDA by SimpleDocs
Landlord Caused Delays. If Tenant's applications for Government Approvals are denied or delayed due to any violations or other contingencies caused by the acts or omissions of Landlord or its employee, agents or other tenants, the obligation to pay rent either under this Lease or the 1993 Lease shall be abated pending Landlord's removal of such violations or contingencies. If Landlord elects not to remove such violations or contingencies, Landlord or Tenant may cancel this Lease in accordance with Article 17, and the 1993 Lease will continue in accordance with its terms, subject to the amended notification and term provisions as set forth herein.
Sample 1
Landlord Caused Delays. To the extent there shall be a delay or there are delays in the “Substantial Completion of the Tenant Improvements,” as that term is defined in Section 7.3, below, due to a “Landlord Caused Delay,” then the Commencement Date shall be extended for each “Landlord Delay Day,” as that term is defined in Section 7.2, below. As used in this Exhibit B and subject to the qualifications and conditions set out in Section 7.2 below, the term “Landlord Caused Delay” shall mean actual delays to the extent resulting from: (i) any material and unreasonable interference by Landlord, its agents, employees or contractors with the Substantial Completion of the Tenant Improvements and which objectively preclude or delay the construction of tenant improvements in the Building by any person, which interference relates to access by Tenant, or the Contractor to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; or (ii) Landlord’s failure to pay any sums out of the Allowance which are properly due and payable under the terms of Section 5.2 of this Exhibit B and which do not relate to any request for payment which is being contested in good faith by Landlord.
Sample 1
Landlord Caused Delays. The Lease Commencement Date shall occur as provided in Section 2.1 of this Lease and Section 3.2 of the Summary, provided that the Lease Commencement Date shall be extended (but
Sample 1
Landlord Caused Delays. Each Lease Commencement Date shall occur as provided in Section 2.1 of this Lease, provided that each Lease Commencement Date shall be extended by the number of days of delay of the Substantial Completion of the Tenant Improvements, as that term is defined in Section 5.3, below, in the applicable portion of the Premises to the extent (i) caused by a Landlord Caused Delay, as that term is defined below, and (ii) the subject delay causes the Substantial Completion of the Tenant Improvements to occur after March 1, 2020. As used herein, the term "Landlord Caused Delay" shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (a) material and unreasonable interference by Landlord, its agents or other Landlord Parties (except as otherwise allowed under this Tenant Work Letter) with the Substantial Completion of the Tenant Improvements which objectively precludes or delays the construction of Tenant Improvements, which interference relates to access by Tenant, or Tenant's Agents to the Building or any Critical Common Areas or service (including temporary power) during normal construction hours, or the use thereof during normal construction hours, and (b) delays due to the acts or failures to act of Landlord with respect to payment of the Tenant Improvement Allowance (except as otherwise allowed under this Tenant Work Letter).
Sample 1

Related to Landlord Caused Delays

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.

  • Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.

  • Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.

  • Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

  • Tenant’s Termination Right If the part of the Buildings or the Real Property so acquired or condemned contains a substantial part of the total area of the portion of the Premises located in such Building immediately prior to such acquisition or condemnation, or if, by reason of such acquisition or condemnation, Tenant no longer has reasonable means of access to the Premises, Tenant may terminate this Lease as to such portion of the Premises by notice to Landlord given within 60 days following the date upon which Tenant received notice of such acquisition or condemnation; provided, however, that if the portion of the Premises so affected shall be the Music Hall, then Tenant’s right of termination shall apply to the whole of the Premises. Furthermore, if by virtue of the nature of the space in the Music Hall which is acquired or condemned, the space remaining in the Music Hall after giving effect to such acquisition or condemnation cannot economically be used for its intended purpose, following the date upon which Tenant received notice of such acquisition or condemnation, Tenant may terminate this Lease by notice to Landlord. If Tenant so notifies Landlord, this Lease shall terminate and the Term shall end and expire upon the date set forth in the notice as to the portion of the Premises covered thereby, which date shall not be more than 30 days following the giving of such notice. If a part of the Premises shall be so acquired or condemned and this Lease and the Term shall not be terminated in accordance with this Section, Landlord, at Landlord’s expense but without requiring Landlord to spend more than it collects as an award, shall, subject to the provisions of any Mortgage or Superior Lease, restore such portion of the Premises not so acquired or condemned to a self-contained unit substantially equivalent (with respect to character, quality, appearance and services) to that which existed immediately prior to such acquisition or condemnation, to the extent commercially practicable to do so, in which case Tenant shall be obligated to restore Tenant’s Property relating to such portion of the Premises to the condition which existed immediately prior to such acquisition or condemnation.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!