DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION Sample Clauses

DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION. If the CONTRACTOR is of the opinion that (a) the work necessary or required to accomplish the result intended by this Contract, or (b) any work ordered to be done as Contract Work by the OWNER is Extra Work and not Contract Work, or
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION. If the CONTRACTOR is of the opinion that (a) the work necessary or required to accomplish the result intended by this Contract, or (b) any work ordered to be done as Contract Work by the OWNER is Extra Work and not Contract Work, or (c) any determination or order of the OWNER violates the terms and provisions of this Contract, the CONTRACTOR shall promptly, either before proceeding with such work or complying with such order or determination, notify the OWNER in writing of his contentions with respect thereto and request a final determination thereof. Such determination of the OWNER shall be given in writing to the CONTRACTOR. If the OWNER determines that the work in question is Extra Work and not Contract Work, or that the order complained of requires performance by the CONTRACTOR beyond that required by the Contract or violates the terms and provisions of the Contract, thereupon the OWNER shall cause either (a) the issuance of a written Change Order covering the Extra Work as provided herein, or
Sample 1Sample 2Sample 3
DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION. If the CONTRACTOR is of the opinion that (a) the work necessary or required to accomplish the result intended by this Contract, or (b) any work ordered to be done as Contract Work by the OWNER is extra work or additional work and not Contract Work, or (c) any determination or order of the OWNER violates the terms and provisions of this Contract, the CONTRACTOR shall promptly, either before proceeding with such work or complying with such order or determination, notify the OWNER in writing of his contentions with respect thereto and request a final determination thereof. Such determination of the OWNER shall be given in writing to the CONTRACTOR. If the OWNER determines that the work in question is Extra Work and not Contract Work, or that the order complained of requires performance by the CONTRACTOR beyond that required by the Contract or violates the terms and provisions of the Contract, thereupon the OWNER shall cause either (a) the issuance of a written Change Order covering the Extra Work as provided herein, or (b) the determination or order complained of to be rescinded or so modified so as to not require performance beyond that required by the terms and provisions of the Contract. If the OWNER determines that the work in question is Contract Work and not Extra Work, or that the determination or order complained of does not require performance by the CONTRACTOR beyond that required by the Contract or violate the terms and provisions of the Contract, he shall direct the CONTRACTOR to proceed, and the CONTRACTOR must promptly comply. In order to reserve his right to claim compensation for such work resulting from such compliance, however, the CONTRACTOR must, within 20 calendar days after receiving the OWNER’S determination and direction, notify the OWNER in writing that the work is being performed, or that the determination and direction is being complied with, under protest. If the CONTRACTOR fails to so appeal to the OWNER for a determination or, having so appealed, should the CONTRACTOR thus fail to notify the OWNER in writing of his protest, the CONTRACTOR shall be deemed to have waived any claim for extra compensation or damages therefore. No oral appeals or oral protests, no matter to whom made, shall be deemed even substantial compliance with the provisions of this item. In addition to the foregoing requirements, the CONTRACTOR shall, upon notice from the OWNER, produce for examination for a minimum period of three (3) years following final pay...
Sample 1Sample 2
DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION. A. If the CONTRACTOR is of the opinion that (a) the work necessary or required to accomplish the result intended by this Contract, or (b) any work ordered to be done as Contract Work by the OWNER is extra work or additional work and not Contract Work, or (c) any determination or order of the OWNER violates the terms and provisions of this Contract, the CONTRACTOR shall promptly, either before proceeding with such work or complying with such order or determination, notify the OWNER in writing of his contentions with respect xxxxxxx and request a final determination thereof.
Sample 1

Related to DISPUTED WORK AND CLAIMS FOR ADDITIONAL COMPENSATION

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • Claims for Additional Time 1 If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Compensation Claims Section 1. When an injury is reported the reference number will be given to the employee and when requested, a copy of the injury report will be furnished to the employee within two (2) working days of such request. A copy of the injury report will also be furnished to the Local Union if requested by a Local Union official. The Employer agrees to cooperate and make a reasonable effort to provide the disposition of employee on-the-job injury claims within ten (10) business days. No employee will be disciplined or threatened with discipline or retaliated against as a result of filing an on-the-job injury report. The Employer or its designee shall not visit an injured worker at his/her their home. The Employer shall provide the Union Co-chair of the National Safety and Health Committee with current summaries of the essential functions of all positions covered by this Agreement. The Union shall have the right to challenge any such summary through the applicable grievance procedure. Any employee who is adversely affected by any such summary shall have the right to challenge such summary through the applicable grievance procedure. Any such decisions or settlements rendered through the grievance procedure, including but not limited to, at arbitration, shall be based solely upon, and applicable to, the facts present in that individual case and shall have no precedential effect beyond that case. This stipulation is limited to cases involving or referencing essential job functions. The Employer shall provide Worker’s Compensation protection for all employees even though not required by state law or the equivalent thereof if the injury arose out of or in the course of employment. An employee who is injured on the job, and is sent home, or to a hospital, or who must obtain medical attention, shall receive pay at the applicable hourly rate for the balance of his/her their regular shift on that day. Upon receiving an employee’s timely report of injury, the Employer shall not pressure an employee to continue to work, nor shall the Employer interfere with an employee seeking medical attention. When, because of such pressure, an employee spends time in a clinic after his or her their normal finish time, the time spent shall be the subject of a pay claim through the grievance procedure. An employee who has returned to regular duties after sustaining a compensable injury, and who is required by the Worker’s Compensation doctor to receive additional medical treatment during the employee’s regularly scheduled working hours, shall receive the employee’s regular hourly rate of pay for such time. The Employer agrees to provide any employee injured locally immediate transportation, at the time of injury, from the job to the nearest appropriate medical facility and return to the job, or to the employee’s home, if required. In such cases, no representative of the Employer shall be permitted to accompany the injured worker while he/she is they are receiving medical treatment and/or being examined by the medical provider, without the employee’s consent. In the event that any employee sustains an occupational illness or injury while on a run away from the home terminal, the Employer shall obtain medical treatment for the employee, if necessary, and, thereafter, will provide transportation by bus, train, plane or automobile to the employee’s home terminal, if and when directed by a doctor. An employee that has a change in his/her their medical duty status shall report that change to the Employer. In the event of a fatality, arising in the course of employment while away from the home terminal, the Employer shall return the deceased to the home of the deceased at the point of domicile.

  • Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!