DISPUTES IN THE CONSTRUCTION INDUSTRY Sample Clauses

DISPUTES IN THE CONSTRUCTION INDUSTRY. The Building and Construction Trades Department, AFL-CIO, on behalf of its fifteen affiliated National and International Unions and their Local Unions, have joined with five employer associations 1 to establish the Plan for the Settlement of Jurisdictional Disputes in the Construction Industry (the Plan). The jurisdictional disputes procedure has been in effect since 1984 and replaced such predecessor plans as the Impartial Jurisdictional Disputes Board and the National Joint Board. The Building and Construction Trades Department’s Constitution requires all jurisdictional disputes between crafts to be settled pursuant to the Plan. As the Plan is a voluntary dispute resolution mechanism, however, a case will not be processed unless the employer agrees to be bound to the Plan. When a jurisdictional dispute arises, the National or International unions have five days to resolve the matter. Anytime within the five day period, the involved National or International Unions or the contractor responsible for making the assignment may request the matter be arbitrated. The parties then have three days to select an arbitrator from a permanent panel of arbitrators knowledgeable in the construction industry. Once selected, the arbitrator must hold the hearing within seven days. The arbitrator issues a decision within three days of the close of the hearing. 3 The arbitrator may not award back pay or damages for miss-assignment of work nor may any party bring an independent action for damages based on the arbitrator’s award. The losing party pays the fees and expenses of the arbitrator. The arbitrator’s decision is final and binding. There is no appeal procedure. The Plan prohibits work stoppages, slowdowns, NLRB and court actions, and grievances under a collective bargaining agreement where the issue involves a jurisdictional dispute or assignment of work by a stipulated contractor. If a union engages in such activity, the Plan provides for expedited arbitration to resolve the matter. Upon notice by the contractor of an impediment to job progress, the Administrator informs the appropriate General President. If the General President is unable to stop the impediment, the Administrator selects an arbitrator to hold a hearing within 24 hours. The sole issues at the hearing is whether there has been an impediment to job progress. The arbitrator must issue a decision within three hours after the close of the hearing. If court enforcement of arbitrator’s decision is necessary, ...
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
DISPUTES IN THE CONSTRUCTION INDUSTRY. The Building and Construction Trades Department, AFL-CIO, on behalf of its fifteen affiliated National and International Unions and their Local Unions, have joined with five employer associations;
Sample 1Sample 2

Related to DISPUTES IN THE CONSTRUCTION INDUSTRY

  • Disputes between the Contracting Parties (1) Disputes between the Contracting Parties concerning the interpretation or application of this I Agreement should, as far as possible, be settled through negotiation. (2) If a dispute between the Contracting Parties cannot thus be settled within six months from the ist time the dispute arose, it shall upon the request of either Contracting Party be submitted to an arbitral tribunal. (3) Such an arbitral tribunal shall be constituted for each individual case in the following way. by Within two months of the receipt of the request for arbitration, each Contracting Party shall appoint one its member of the tribunal. Those two members shall then select a national of a third State who on approval by the two Contracting Parties shall be appointed Chairman of the tribunal. The Chairman shall be appointed within two months from the date of appointment of the other two members. (4) If within the periods specified in paragraph (3) of this Article the necessary appointments have in not been made, either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make any necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice President shall be invited to make the necessary appointments. If the Vice President is a national of either Contracting Party or if he too is prevented from discharging the said function, the Member of the International Court of Justice next in seniority who is not a national of either Contracting Party shall be invited to make the necessary appointments. (5) The arbitral tribunal shall reach its decision by a majority of votes. Such decisions shall be binding on both Contracting Parties. Each Contracting Party shall bear the cost of its own member of the tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining costs shall be borne in equal parts by the Contracting Parties. The tribunal may, however, in its decision direct that a higher proportion of costs shall be borne by one of the two Contracting Parties, and this award shall be binding on both Contracting Parties. The tribunal shall determine its own procedures.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Pre-Construction Conference Participate in a Pre-Construction Conference prior to commencement of Work at the Site.

  • Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.

  • Disputes Concerning Work or Cost Any dispute concerning the work hereunder or additional costs, or any non-procurement issues shall be settled in accordance with 43 Texas Administrative Code §9.2.

  • Settlement of Disputes between the Contracting Parties 1. Disputes between the Contracting Parties concerning the interpretation or application of this Agreement should, if possible, be settled through diplomatic channels. 2. If a dispute between the contracting Parties cannot thus be settled, it shall upon the request of either Contracting Party be submitted to an arbitral tribunal. 3. Such as arbitral tribunal shall be constituted for each individual case in the following way. Within two months of the receipt of the request for arbitration, each Contracting Party shall appoint one member of the tribunal. Those two members shall then select a national of a third State who an approval by the two Contracting Parties shall be appointed Chairman of the tribunal. The Chairman shall be appointed within two months from the date of appointment of the other two members. 4. If within the periods specified in paragraph 3 of this Article the necessary appointments have not been made either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make any necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice-President shall be invited to make the necessary appointments. If the vice- President is a national of either Contracting Party or if he too is prevented form discharging the said function, the members of the International Court of Justice next in seniority who is not a national of either Contracting Party Shall be invited to make the necessary appointments. 5. The arbitral tribunal shall reach its decision by a majority of votes. Such decision shall be binding on both Contracting Parties. Each Contracting Party shall bear the cost of its own member of the tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining cost shall be borne in equal parts by the Contracting Parties. The tribunal may, however, in its decision direct that a higher proportion of costs shall be borne by one of the two Contracting Parties, and this award shall be binding on both Contracting Parties. The tribunal shall determine its won procedure.

  • Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.

  • Interpretation; Construction The headings set forth in this Agreement are for convenience only and shall not be used in interpreting this Agreement. This Agreement has been drafted by legal counsel representing Company, but Executive has participated in the negotiation of its terms. Furthermore, Executive acknowledges that Executive has had an opportunity to review and revise the Agreement and have it reviewed by legal counsel, if desired, and, therefore, the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Agreement.

  • Interpretation and Rules of Construction In this Agreement, except to the extent otherwise provided or that the context otherwise requires: (a) when a reference is made in this Agreement to an Article, Section, Exhibit or Schedule, such reference is to an Article or Section of, or an Exhibit or Schedule to, this Agreement unless otherwise indicated; (b) the table of contents and headings for this Agreement are for reference purposes only and do not affect in any way the meaning or interpretation of this Agreement; (c) whenever the words “include,” “includes” or “including” are used in this Agreement, they are deemed to be followed by the words “without limitation”; (d) the words “hereof,” “herein” and “hereunder” and words of similar import, when used in this Agreement, refer to this Agreement as a whole and not to any particular provision of this Agreement; (e) all terms defined in this Agreement have the defined meanings when used in any certificate or other document made or delivered pursuant hereto, unless otherwise defined therein; (f) the definitions contained in this Agreement are applicable to the singular as well as the plural forms of such terms; (g) references to a Person are also to its successors and permitted assigns; and (h) the use of “or” is not intended to be exclusive unless expressly indicated otherwise.

  • Interpretation and Construction When a reference is made in this Agreement to a Section, such reference shall be to a Section of this Agreement, unless otherwise indicated. The headings contained in this Agreement are for reference purposes only and shall not affect in any way the meaning or interpretation of this Agreement. Whenever the words “include,” “includes” and “including” are used in this Agreement, they shall be deemed to be followed by the words “without limitation.” The words “hereof, “herein” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision of this Agreement. The word “will” shall be construed to have the same meaning as the word “shall.” The words “dates hereof” will refer to the date of this Agreement. The word “or” is not exclusive. The definitions contained in this Agreement are applicable to the singular as well as the plural forms of such terms. Any agreement, instrument, law, rule or statute defined or referred to herein means, unless otherwise indicated, such agreement, instrument, law, rule or statute as from time to time amended, modified or supplemented. Each of the parties hereto acknowledges that it has been represented by counsel of its choice throughout all negotiations that have preceded the execution of this Agreement, and that it has executed the same with the advice of said independent counsel. Each party cooperated and participated in the drafting and preparation of this Agreement and the documents referred to herein, and any and all drafts relating thereto exchanged among the parties shall be deemed the work product of all of the parties and may not be construed against any party by reason of its drafting or preparation. Accordingly, any rule of law or any legal decision that would require interpretation of any ambiguities in this Agreement against any party that drafted or prepared it is of no application and is hereby expressly waived by each of the parties hereto, and any controversy over interpretations of this Agreement shall be decided without regards to events of drafting or preparation.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!