SPECIAL DELIVERY INSTRUCTIONS All shipments will be FOB destination (as specified on Ordering Entity Purchase Order).
Distance Learning Distance learning is a teaching modality whereby all or the majority of instruction and student interaction occurs via electronic media or equivalent mechanisms with the Faculty and students physically separated from each other. This includes courses that are fully online as well as Live online, hybrid, flipped, computer-based courses, and other alternate delivery methods.
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
Material Delivery Within 60 days after award date, Purchaser shall provide Forest Service a written schedule showing the desired delivery dates of any material to be supplied by Forest Service. With reasonable notice, schedule may be amended by agreement. Forest Service agrees to make delivery within 15 days after the scheduled delivery dates that are at least 60 days after the schedule is submitted, unless prevented by causes beyond control of Forest Service. If Purchaser does not provide Forest Service the written schedule within the period provided in this Subsection, Forest Service agrees to make delivery within 90 days after a late schedule is submitted, unless prevented by causes beyond control of Forest Service. After delivery to and written receipt by Purchaser, Purchaser is responsible for installation of needed material and for any loss of or damage to such material due to Purchaser's negligence prior to installation or return of unused material to Forest Service. At Purchaser’s option, Forest Service deliveries shall be to Purchaser’s storage area, as agreed, or to the nearest practicable point to the job site along existing roads. Unused material shall be returned to Forest Service at location of delivery, unless agreed otherwise.
Conversion of Live Telephone Exchange Service to Analog 2W Loops The following coordination procedures shall apply to “live” cutovers of VERIZON Customers who are converting their Telephone Exchange Services to SPRINT Telephone Exchange Services provisioned over Analog 2W unbundled Local Loops (“Analog 2W Loops”) to be provided by VERIZON to SPRINT.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Website, Email Address and Toll-Free Number The Administrator will establish and maintain and use an internet website to post information of interest to Class Members including the date, time and location for the Final Approval Hearing and copies of the Settlement Agreement, Motion for Preliminary Approval, the Preliminary Approval, the Class Notice, the Motion for Final Approval, the Motion for Class Counsel Fees Payment, Class Counsel Litigation Expenses Payment and Class Representative Service Payment, the Final Approval and the Judgment. The Administrator will also maintain and monitor an email address and a toll-free telephone number to receive Class Member calls, faxes and emails.
Providing Notice of Breaches 8.1 If Covered Entity determines that an impermissible acquisition, access, use or disclosure of PHI for which one of Business Associate’s employees or agents was responsible constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity, Business Associate shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When requested to provide notice, Business Associate shall consult with Covered Entity about the timeliness, content and method of notice, and shall receive Covered Entity’s approval concerning these elements. The cost of notice and related remedies shall be borne by Business Associate.
Reducing Text Messaging While Driving Pursuant to Executive Order 13513, 74 FR 51225 (Oct. 6, 2009), Recipient should encourage its employees, subrecipients, and contractors to adopt and enforce policies that ban text messaging while driving, and Recipient should establish workplace safety policies to decrease accidents caused by distracted drivers.
The OCN, From XXX, and Invoice Number will control the invoice sequencing The From XXX will be used to identify to <<customer_name>> which BellSouth XXX is sending the message. BellSouth and <<customer_name>> will use the invoice sequencing to control data exchange. BellSouth will be notified of sequence failures identified by <<customer_name>> and resend the data as appropriate. THE DATA WILL BE PACKED USING ATIS EMI RECORDS.
