District Consultants Sample Clauses

District Consultants. Except to the extent of design consultants retained by the Architect, other consultants required or desired by the DISTRICT in connection with the Project shall be retained and paid for by the DISTRICT. Such other consultants include, but may not be limited to, legal counsel, insurance/surety consultants, audio-visual equipment/installation consultants, and hazardous material assessment & abatement consultants.
Sample 1Sample 2See All (7)
District Consultants. Except for the Sub-Consultants retained by the Architect, the District shall furnish all legal, accounting, insurance and other consulting services as may be necessary for the Project.
Sample 1Sample 2Sample 3See All (6)
District Consultants. The District will furnish all legal, accounting, insurance and other consulting services as may be necessary for the Project
Sample 1Sample 2See All (5)
District Consultants. Except for Design Consultants retained by the Architect under this Agreement, the District shall furnish all legal, accounting, insurance and other consulting services as may be necessary for Project design, bidding and construction. The District will make the sole determination of the consultants needed.
Sample 1
District Consultants. The District reserves the rights to employ other consultants in connection with the Project and to perform work related to the Project with its own forces. The Construction Manager shall notify the District in the event any such consultant or the District’s work forces have unreasonably interfered, or will unreasonably interfere, with the Construction Manager’s responsibilities pursuant to this CM Agreement. Upon receipt of any such notification, the District shall have the option to: (i) immediately cause the consultant or the District’s forces to cease the activities causing such unreasonable interference; (ii) waive all rights the District may have against Construction Manager in regard to the effect of such activities, including, without limitation, claims for delay; (iii) amend this CM Agreement and/or the Scope of CM Services to eliminate any existing or potential interference with the CM Services, in which event, if applicable, the Construction Manager’s compensation hereunder shall be adjusted accordingly; or (iv) if the District disagrees with the Construction Manager’s conclusion that District forces or consultants have unreasonably interfered, or will unreasonably interfere, with the CM Services, the District may decline to take action, in which event the Construction Manager may, in its discretion, pursue dispute resolution pursuant to Section 11.2 of this CM Agreement. In the event the Construction Manager pursues dispute resolution as described in item (iv) of the foregoing sentence, the Construction Manager shall continue to provide the CM Services in strict accordance with this CM Agreement during the pending dispute resolution process.
Sample 1
District Consultants. District shall have the right, but not the obligation, to retain District Consultants to review and/or approve Shop Drawings, Product Data and Samples and other Submittals. Such action will be taken with such promptness as to cause no unreasonable Delay in the Work. A District Consultant’s review, approval or other action upon the Design-Build Entity's Submittals shall be for the limited purpose of checking for conformance with the Design Intent and is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Design- Build Entity as required by the Contract Documents.
Sample 1

Related to District Consultants

  • Sub-Consultants All sub-consultants shall comply with each and every insurance provision of this Section 3.

  • Subconsultants Whichever of the following is marked applies to this Approved Service Order: The Consultant can not use any subconsultants. The Consultant can use the following subconsultants to assist in providing the required services and deliverables: 2. 3.

  • Contract for Professional Services of Physicians, Optometrists, and Registered Nurses In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 2254.008(a)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • Consultants Any and all consultant(s), sub-consultant(s), subcontractor(s), or agent(s) to the Architect.

  • Technicians All other technicians and support personnel will be paid at the Tender rate.

  • DIPLOMATIC AGENTS AND CONSULAR OFFICERS Nothing in this Agreement shall affect the fiscal privileges of diplomatic agents or consular officers under the general rules of international law or under the provisions of special agreements.

  • Personnel Provide, without remuneration from or other cost to the Trust, the services of individuals competent to perform the administrative functions which are not performed by employees or other agents engaged by the Trust or by the Adviser acting in some other capacity pursuant to a separate agreement or arrangement with the Trust.

  • Programs and Services Every aspect of the service you provide is considered part of your program, and therefore it must be accessible to individuals with disabilities. This includes parking lots, service counters and spaces, transportation (shuttles, etc.), agendas, flyers, emails, online services, phone calls, meetings, celebrations, classes, recreational activities and more. The guidance in this document is primarily intended to help you provide accessible programs by providing you with the tools to: ▪ survey facilities and identify common architectural barriers for people with disabilities; ▪ identify common ADA compliance problems in your communications and activities; and ▪ remove barriers and fix common ADA compliance problems in these areas. Your programs can be broken into three main categories, (Communications, Facilities, and Activities) which will be covered in more detail below.

  • Professionals For projects involving installation or construction services, the Grantee agrees that only licensed professionals will be used to perform services under this Grant Agreement where such services are called for and licensed professionals are required for those services under State law.

  • Employees and Consultants Pubco does not have any employees or consultants, except as disclosed in the Pubco SEC Documents.