Amending of Time Limits The time limits fixed in both the grievance and arbitration procedure may be extended by consent of the parties.
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.
Time Limits Each party involved in a grievance shall act quickly so that the grievance may be resolved promptly. Every effort should be made to complete action within the time limits contained in the grievance procedure. However, with the mutual consent of the parties, the time limitation for any step may be extended.
Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
Extension of Time; Waiver At any time prior to the Effective Time, the parties may, by action taken or authorized by their respective Boards of Directors, to the extent permitted by applicable Law, (a) extend the time for the performance of any of the obligations or acts of the other parties, (b) waive any inaccuracies in the representations and warranties of the other parties set forth in this Agreement or any document delivered pursuant hereto or (c) subject to applicable Law, waive compliance with any of the agreements or conditions of the other parties contained herein; provided, however, that after the Company Stockholder Approval has been obtained, no waiver may be made that pursuant to applicable Law requires further approval or adoption by the Stockholders without such further approval or adoption. Any agreement on the part of a party to any such waiver shall be valid only if set forth in a written instrument executed and delivered by a duly authorized officer on behalf of such party. No failure or delay of any party in exercising any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, or any course of conduct, preclude any other or further exercise thereof or the exercise of any other right or power. The rights and remedies of the parties hereunder are cumulative and are not exclusive of any rights or remedies which they would otherwise have hereunder.
Time Limit Should the Local Church fail to satisfy all of its obligations set forth herein by December 31, 2023, this Disaffiliation Agreement shall be null and void.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Time Limitation The time limits established in the grievance procedures shall be followed by the parties and the aggrieved employee. If the time limit procedure is not followed by the Union or the aggrieved employee, the grievance shall be considered settled without precedent. If the time procedure is not followed by the Employer, the grievance shall automatically advance to the next step, but arbitration shall only be instituted upon timely written notice by the Union. The time limits established in the grievance and arbitration procedure may be extended by mutual agreement reduced to writing and signed by the parties.
Time of the Essence; Computation of Time Time is of the essence for each and every provision of this Agreement. Whenever the last day for the exercise of any privilege or the discharge or any duty hereunder shall fall upon a Saturday, Sunday, or any date on which banks in New York, New York are authorized to be closed, the party having such privilege or duty may exercise such privilege or discharge such duty on the next succeeding day which is a regular business day.
