Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
34.2 Except in case of Force Majeure, as provided under GCC Clause 32, a delay by the Supplier in the performance of its Delivery and Completion obligations shall render the Supplier liable to the imposition of liquidated damages pursuant to GCC Clause 26, unless an extension of time is agreed upon, pursuant to GCC Sub-Clause 34.1.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
8.3.2 Any claim for extension of time shall be made in writing to the Architect not more than twenty days after the commencement of the delay; otherwise it shall be waived. In the case of a continuing delay only one claim is necessary. The Contractor shall provide an estimate of the probable effect of such delay on the progress of the Work.
8.3.3 This Paragraph 8.3 does not exclude the recovery of damages for delay by either party under other provisions of the Contract Documents.
Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP.
(b) The terms defined in this Article include the plural as well as the singular.
(c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.
Other Provisions of General Application Section 7.1 Notices to the Rights Agent, Parent and the Stockholders’ Representative. Any notice, request, instruction or other document to be given hereunder by any party to the others shall be in writing and delivered personally or sent by registered or certified mail, postage prepaid, by electronic mail (except with respect to the Rights Agent), by facsimile transmission only with respect to the Rights Agent or overnight courier, provided that with respect to notices deliverable to the Stockholders’ Representative, such notices shall be delivered solely via electronic mail or facsimile: If to Parent or the Company: Eros International Plc First Names House Victoria Road Xxxxxxx Isle of Man IM2 4DF British Isles Attention: Xxxx Xxxxxxx, Chief Corporate and Strategy Officer Email: xxxx.xxxxxxx@xxxxxxxx.xxx with a copy (which shall not constitute notice) to: Xxxxxx, Xxxx & Xxxxxxxx LLP 000 Xxxxx Xxxxx Xxxxxx Xxx Xxxxxxx, Xxxxxxxxxx 00000-0000 Attention: Xxxxx Xxxxxx Xxxxx Xxxxxx Email: xxxxxxx@xxxxxxxxxx.xxx xxxxxxx@xxxxxxxxxx.xxx If to the Rights Agent: Computershare Trust Company, N.A., Computershare Inc. 000 Xxxxxx Xxxxxx Canton, MA 02021 Attention: Client Services Facsimile: (000) 000-0000 If to the Stockholders’ Representative: Fortis Advisors LLC Attention: Notices Department (Project World Cup) Email: xxxxxxx@xxxxxxxxx.xxx Facsimile: (000) 000-0000 with a copy (which shall not constitute notice) to: Xxxxxxxx & Xxxxx LLP 000 Xxxxx Xxxxxx Xxxxxx, Xxxxx 0000 Xxx Xxxxxxx, Xxxxxxxxxx 00000 Attention: Xxxx X. Xxxxxx, P.C. Email: xxxx.xxxxxx@xxxxxxxx.xxx or to such other persons or addresses as may be designated in writing by the party to receive such notice as provided above. Any notice, request, instruction or other document given as provided above shall be deemed given to the receiving party upon actual receipt, if delivered personally; three (3) business days after deposit in the mail, if sent by registered or certified mail; upon confirmation of successful transmission if sent by electronic mail; or on the next business day after deposit with an overnight courier, if sent by an overnight courier.
Provisions of the Plan This option is subject to the provisions of the Plan, a copy of which is furnished to the Participant with this option.
Concerning Applicable Provisions of Law, etc This Agreement shall be subject to all applicable provisions of law, including the applicable provisions of the 1940 Act and to the extent that any provisions herein contained conflict with any such applicable provisions of law, the latter shall control.
Class Proceedings and Consolidations No party hereto shall be entitled to join or consolidate disputes by or against others in any arbitration, except parties who have executed any Loan Document, or to include in any arbitration any dispute as a representative or member of a class, or to act in any arbitration in the interest of the general public or in a private attorney general capacity.
Conditions of the Obligations of the Underwriter The obligations of the Underwriter hereunder shall be subject to the accuracy of the representations and warranties on the part of the Company set forth in Section 2 hereof, in each case as of the date hereof and as of each Closing Date as though then made, to the timely performance by each of the Company of its covenants and other obligations hereunder on and as of such dates, and to each of the following additional conditions:
General Obligations of the Parties A. Recognition of Higher Education Partner, Promotion, Marketing, and Advertising
1) When reporting and publicizing high school students’ completion of dual credit courses, degrees, or certificates, Xxxxxxx ISD will recognize Collin College as their higher education partner awarding college credit. Both Parties agree not to use the other Party’s name, logo, or likeness in any press release, marketing materials, or other public announcements without receiving prior written approval from an authorized designee.
B. Understanding of the Parties
1) Both parties understand the safety and security risks inherent with minors and agree that certain risks may be unforeseeable. Further, the Parties agree that the public safety departments from both Collin College and Xxxxxxx ISD will collaborate to develop and/or review safety and security standards and/or guidelines, including emergency response.
2) In accordance with FERPA, Collin College and Xxxxxxx ISD will protect students’ privacy and guard against the unauthorized release of identifying student information and records, and comply with all applicable requirements of FERPA.
Conditions of the Obligations of the Underwriters The obligations of the several Underwriters to purchase and pay for the Firm Securities on the First Closing Date and the Optional Securities to be purchased on each Optional Closing Date will be subject to the accuracy of the representations and warranties of the Company herein (as though made on such Closing Date), to the accuracy of the statements of Company officers made pursuant to the provisions hereof, to the performance by the Company of its obligations hereunder and to the following additional conditions precedent:
