Feasible Schedule Sample Clauses

Feasible Schedule. The Landlord has carefully examined and analyzed the site, the Conceptual Plans and Specifications and all factors related to its proposal for the Landlord’s Work and agrees that the Substantial Completion Date is feasible and reasonable. The Landlord further agrees that, the Landlord and the Design/Builder are better able than the Tenant, the Tenant’s consultants or any other of the Tenant’s representatives to provide the services herein for the Tenant in the Tenant’s best interest, and to assess such feasibility and reasonableness, and do fully accept the risks of substantially completing the Landlord’s Work prior to the Substantial Completion Date, subject to the other terms and conditions of this Lease Agreement. (i) Independent Architect. Any disputes arising in connection with the approvals required under this Section 2.3, consistency of each of the phases of plans and specifications under Subsections 2.3(b) and (d) above, or errors and omissions from previously approved plans and specifications shall be referred to Hellmuth, Obata & Kassabaum (the “Independent Architect”) for binding arbitration. These binding arbitration proceedings shall be conducted in Tampa, Florida, and the parties acknowledge that Design/Builder shall be included as a party to the binding arbitration. With respect to any binding arbitration conducted under this Section, the Independent Architect shall enter a final written decision with five (5) business days of the receipt of the proposed Design Development Documents or the proposed Final Construction Documents, as applicable, and written comments of each party. Neither party can dismiss the Independent Architect from appointment hereunder without the written consent of the other party. Should the Independent Architect be dismissed by mutual agreement of the parties, or should the Independent Architect resign this appointment, a new independent third party architect will be selected by mutual agreement of the parties. The Independent Architect’s reasonable fees and costs shall be shared equally between Landlord and Tenant.
Sample 1
AutoNDA by SimpleDocs
Feasible Schedule. The Landlord has carefully examined and analyzed the site, the Conceptual Plans and Specifications and all factors related to its proposal for the Landlord's Work and agrees that the Substantial Completion Date is feasible and reasonable. The Landlord further agrees that, the Landlord and the Design/Builder are better able than the Tenant, the Tenant's consultants or any other of the Tenant's representatives to provide the services herein for the Tenant in the Tenant's best interest, and to assess such feasibility and reasonableness, and do fully accept the risks of substantially completing the Landlord's Work prior to the Substantial Completion Date, subject to the other terms and conditions of this Lease Agreement.
Sample 1

Related to Feasible Schedule

  • Time Schedule 4.1. A project schedule is included in Appendix A. 4.2. Any delay of services or change in sequence of tasks must be approved in writing by Delaware. 4.3. In the event that Vendor fails to complete the project or any phase thereof within the time specified in the Contract, or with such additional time as may be granted in writing by Delaware, or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this Agreement or any extensions thereof, Delaware shall suspend the payments scheduled as set forth in Appendix A.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Wage Schedule ‌ The pay rate (including increments and stated extras) as agreed to and hereinafter in this Schedule provided, shall be in effect during the term of the Agreement, from April 1, 2019 to March 31, 2022.

  • Flexible Scheduling All posts experience a higher day-time volume than occurs during the night hours and the Parties agree to a flexible scheduling as outlined below to be compatible with the needs of the community served and availability of on-call staff and the members of the post’s full-time staff.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Submittal Schedule Within sixty days after the Effective Date of the Contract, the Contractor shall prepare and submit a Submittal Schedule for review and approval of the Design Professional. In establishing the Submittal Schedule the Contractor shall take into account large submittal documents that will require longer review times, e.g., submittals with over fifty sheets of drawings. The Design Professional’s approval shall be based on conformance of the Submittal Schedule with the Overall Project Schedule, subject to change from time to time in accordance with the progress of the Work.

  • Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.

  • Milestone Schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.

  • Receivable Schedule The information set forth in the Receivable Schedule was true and correct in all material respects as of the close of business on the Cutoff Date, and no selection procedures believed to be adverse to the Depositor and/or the Noteholders were utilized in selecting the Receivables from those retail installment sale contracts which met the criteria contained in this Receivables Purchase Agreement. The information set forth in the data tape or other listing regarding the Receivables made available to the Depositor and its assigns was true and correct in all material respects as of the close of business on the Cutoff Date.

  • Budget Schedule Subrecipient agrees that the expenditures of any and all funds under this Contract will be in accordance with the Budget Schedule, a copy of which is attached hereto as Attachment C, and which by this reference is incorporated herein and made a part hereof as if fully set forth.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!