Final Approval by Tenant Sample Clauses

Final Approval by Tenant. Within ten (10) business days after receipt of Landlord’s written nonbinding cost estimate and description of any Tenant Delay, Tenant shall give written notice to Landlord of its approval thereof or its objections, specifying in detail the nature of its objections. In the latter case, Landlord shall endeavor to modify the Plans to address Tenant’s objections and will resubmit a revised cost estimate and description of any Tenant Delay to Tenant for its approval, and Tenant shall have three (3) business days to approve or object by written notice to Landlord. If Tenant shall not approve, then Landlord shall again endeavor to modify the Plans to address Tenant’s objections and resubmit the Plans, as revised, and a new cost estimate and statement of the Tenant Delays to Tenant, and Tenant shall again have three (3) business days to approve or object. This process shall be repeated until Tenant approves. However, the period following the date (“Scheduled Approval Date”) of expiration of the first three (3) business day period for Tenant’s approval of a revision until the date of Tenant’s approval shall be an element of Tenant Delay, and Tenant shall be responsible for any additional costs incurred by Landlord by reason of such delay. Such modifications and. revisions shall be subject to Landlord’s reasonable approval and shall be in accordance with the standards set forth in Paragraph 1 of this Work Letter Agreement. Tenant’s approval shall constitute authorization to commence the construction of the Tenant Improvements in accordance with the Plans, as modified or revised. Tenant shall signify its final approval by signing a copy of each sheet or page of the Plans and delivering such signed copy to Landlord. If Landlord’s cost estimate of the Tenant Improvements to be constructed in accordance with the Plans exceeds the Tenant Improvement Allowance (as defined below), then Tenant shall follow the provisions for payment to Landlord, as outlined in Paragraph 5(c) of this Work Letter Agreement. If Tenant does not approve the Plans and authorize Landlord to proceed with the construction of the Tenant Improvements by the Scheduled Approval Date, then Tenant shall be charged with all costs incurred by reason of any delay in completion of the construction of Tenant Improvements and such delay shall be an element of Tenant Delay. If Tenant delays final approval and authorization to commence with construction of Tenant Improvements for a period of thirty (30) days bey...
AutoNDA by SimpleDocs
Final Approval by Tenant. Within five (5) days after receipt of the written nonbinding cost estimates prepared by the contractors and any description of any Tenant Delay which Landlord elects to provide to Tenant, Tenant shall either (i) give its written approval thereof and authorization to proceed with construction or (ii) immediately request the architect to modify or revise the Plans in any manner desired by Tenant to decrease the cost of the Tenant Improvements or minimize the amount of the Tenant Delay.

Related to Final Approval by Tenant

  • Final Approval After Acceptance, Engineer shall perform any required modifications, changes, alterations, corrections, redesigns, and additional work necessary to receive Final Approval by the County. "Final Approval" in this sense shall mean formal recognition that the Engineering Services have been fully carried out.

  • Final Approval Order “Final Approval Order” means the Court order that approves this Settlement Agreement and makes such other final rulings as are contemplated by this Settlement Agreement.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Landlord Approval (Check one)

  • Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.

  • MOTION FOR FINAL APPROVAL Not later than 16 court days before the calendared Final Approval Hearing, Plaintiff will file in Court, a motion for final approval of the Settlement that includes a request for approval of the PAGA settlement under Labor Code section 2699, subd. (l), a Proposed Final Approval Order and a proposed Judgment (collectively “Motion for Final Approval”). Plaintiff shall provide drafts of these documents to Defense Counsel not later than seven days prior to filing the Motion for Final Approval. Class Counsel and Defense Counsel will expeditiously meet and confer in person or by telephone, and in good faith, to resolve any disagreements concerning the Motion for Final Approval.

  • Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.

  • New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!