STATEWIDE ACHIEVEMENT TESTING When CONTRACTOR is a NPS, per implementation of Senate Bill 484, CONTRACTOR shall administer all Statewide assessments within the California Assessment of Student Performance and Progress (“CAASPP”), Desired Results Developmental Profile (“DRDP”), California Alternative Assessment (“CAA”), achievement and abilities tests (using LEA-authorized assessment instruments), the Fitness Gram, , the English Language Proficiency Assessments for California (“ELPAC”), and as appropriate to the student, and mandated by LEA pursuant to LEA and state and federal guidelines. CONTRACTOR is subject to the alternative accountability system developed pursuant to Education Code section 52052, in the same manner as public schools. Each LEA student placed with CONTRACTOR by the LEA shall be tested by qualified staff of CONTRACTOR in accordance with that accountability program. XXX shall provide test administration training to CONTRACTOR’S qualified staff. CONTRACTOR shall attend LEA test training and comply with completion of all coding requirements as required by XXX.
Goals Goals define availability, performance and other objectives of Service provisioning and delivery. Goals do not include remedies and failure to meet any Service Goal does not entitle Customer to a Service credit.
Project Goals The schedule, budget, physical, technical and other objectives for the Project shall be defined.
Goals & Objectives The purpose of this Agreement is to ensure that the proper elements and commitments are in place to provide consistent IT service support and delivery to the Customer by Centre. The goal of this Agreement is to obtain mutual agreement for IT service provision between Centre and Customer. The objectives of this Agreement are to: Provide clear reference to service ownership, accountability, roles and/or responsibilities. Present a clear, concise and measurable description of service provision to the Customer. Match perceptions of expected service provision with actual service support & delivery.
Milestones Subject to the provisions of the SGIP, the Parties shall agree on milestones for which each Party is responsible and list them in Attachment 4 of this Agreement. A Party’s obligations under this provision may be extended by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately notify the other Parties of the reason(s) for not meeting the milestone and (1) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (2) requesting appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not unreasonably withhold agreement to such an amendment unless it will suffer significant uncompensated economic or operational harm from the delay, (1) attainment of the same milestone has previously been delayed, or (2) it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.
Contract Goals A. For purposes of this procurement, OGS conducted a comprehensive search and determined that the Contract does not offer sufficient opportunities to set goals for participation by MWBEs as subcontractors, service providers, or suppliers to Contractor. Contractor is, however, encouraged to make every good faith effort to promote and assist the participation of MWBEs on this Contract for the provision of services and materials. The directory of New York State Certified MWBEs can be viewed at: xxxxx://xx.xxxxxxxxxxxxxx.xxx/FrontEnd/VendorSearchPublic.asp?TN=ny&XID=2528. Additionally, following Contract execution, Contractor is encouraged to contact the Division of Minority and Women’s Business Development ((000) 000-0000; (000) 000-0000; or (000) 000-0000) to discuss additional methods of maximizing participation by MWBEs on the Contract.
Targets a) Seller’s supplier diversity spending target for Work supporting the construction of the Project prior to the Commercial Operation Date is ____ percent (___%) as measured relative to Seller’s total expenditures on construction of the Project prior to the Commercial Operation Date, and;
Goals and Objectives The Parties acknowledge and agree that the specific goals and objectives of the Parties in entering into this Agreement are to:
