INDEPENDENT QUALITY FIRM QUALITY ACCEPTANCE REQUIREMENTS‌ Sample Clauses

INDEPENDENT QUALITY FIRM QUALITY ACCEPTANCE REQUIREMENTS‌. 6 The Quality Acceptance on the Project consists of frontline acceptance testing and inspection 7 being performed by the IQF. Owner Verification (OV) and Quality Acceptance together are the 8 basis for the acceptance decision. With regard to materials testing, the IQF-performed Quality 9 Acceptance results may be used in the acceptance decision, provided that they are statistically 10 validated and/or verified by the OV test results (See Section 7 for details about OV). Quality 11 acceptance is performed by the IQF and OV is performed by ADOT or their consultant(s). With 12 regard to workmanship and other inspection driven features of the Work, the IQF’s inspection 13 observations and conclusions may be used in the acceptance decision, provided that OV 14 activities verify the CQMP process, procedure and documentation adherence. 15 Developer’s Quality Acceptance portion of the CQMP must include the procedures used by the 16 IQF to ensure that the Work is inspected and tested to verify compliance with the RFC 17 Documents. 18 Developer’s CQMP must establish a systematic approach to define the processes, methods, 19 procedures, and documentation for the IQF to deliver Quality Acceptance on the Project. These 20 methods and procedures must clearly define the levels of authority and responsibility for the 21 administration of IQF’s Quality Acceptance plan.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
INDEPENDENT QUALITY FIRM QUALITY ACCEPTANCE REQUIREMENTS‌. 27 The Quality Acceptance on Alternative Acceptance projectsthe Project consists of frontline 28 acceptance testing and inspection being performed by the IQF. Owner Verification (OV) and 29 Quality Acceptance together are the basis for the acceptance decision, provided that . With 30 regard to materials testing, the IQF-performed Quality Acceptance results may be used in the 31 acceptance decision, provided that they are statistically validated and/or verified by the OV test 32 results (See Section 97 for details about OV). Quality acceptance is performed by the IQF, and 33 OV is performed by ADOT or their consultant(s). With regard to workmanship and other 34 inspection driven features of the Work, the IQF’s inspection observations and conclusions may 35 be used in the acceptance decision, provided that OV activities verify the CQMP process, 36 procedure and documentation adherence. 37 The Contractor’sDeveloper’s Quality Acceptance portion of the CQMP shallmust include the 38 procedures used by the IQF to ensure that the workWork is inspected and tested to verify 39 compliance with the released-for-construction plans, approved shop drawings, working 40 drawings, and specifications. Contractor’s Quality Acceptance shall be separate from the 41 Contractor’s QC programRFC Documents. 42 Contractor’sDeveloper’s CQMP shallmust establish a systematic approach to define the 43 processes, methods, procedures, and documentation for the IQF to deliver Quality Acceptance 1 on the Project. These methods and procedures shallmust clearly define the levels of authority 2 and responsibility for the administration of IQF’s Quality Acceptance plan. 3 ADOT will be responsible for developing more detailed requirements for the IQF’s Quality 4 Acceptance to be included in the Technical Provisions (TPs) of the Project Request for
Sample 1
INDEPENDENT QUALITY FIRM QUALITY ACCEPTANCE REQUIREMENTS‌ 
Sample 1

Related to INDEPENDENT QUALITY FIRM QUALITY ACCEPTANCE REQUIREMENTS‌

  • Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.

  • Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.

  • Quality Assurance Requirements There are no special Quality Assurance requirements under this Agreement.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Company hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace at the Project Location. The Company will give written notice to the IEDC within ten (10) days after receiving actual notice that the Company, or an employee of the Company in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of payments under the Agreement, termination of the Agreement and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in the Agreement is in excess of $25,000.00, the Company agrees that it will provide a drug-free workplace by: A. Publishing and providing to all of its employees a statement notifying them that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Company’s workplace, and specifying the actions that will be taken against employees for violations of such prohibition;

  • CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Escrow Format Specification Deposit’s Format. Registry objects, such as domains, contacts, name servers, registrars, etc. will be compiled into a file constructed as described in draft-xxxxx-xxxxxxx-registry-data-escrow, see Part A, Section 9, reference 1 of this Specification and draft-xxxxx-xxxxxxx-dnrd-objects-mapping, see Part A, Section 9, reference 2 of this Specification (collectively, the “DNDE Specification”). The DNDE Specification describes some elements as optional; Registry Operator will include those elements in the Deposits if they are available. If not already an RFC, Registry Operator will use the most recent draft version of the DNDE Specification available at the Effective Date. Registry Operator may at its election use newer versions of the DNDE Specification after the Effective Date. Once the DNDE Specification is published as an RFC, Registry Operator will implement that version of the DNDE Specification, no later than one hundred eighty (180) calendar days after. UTF-8 character encoding will be used.

  • Quality Assurance Program An employee shall be entitled to leave of absence without loss of earnings from her or his regularly scheduled working hours for the purpose of writing examinations required by the College of Nurses of Ontario arising out of the Quality Assurance Program.

  • Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones: 6.1 Substantial Site work completed. On or before December 31, 2020 Interconnection Customer must demonstrate completion of at least 20% of project site construction. At this time, Interconnection Customer must submit to Interconnected Transmission Owner and Transmission Provider initial drawings, certified by a professional engineer, of the Customer Interconnection Facilities. 6.2 Delivery of major electrical equipment. On or before December 31, 2021, Interconnection Customer must demonstrate that all generating units have been delivered to Interconnection Customer’s project site.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!