INSPECTION/TESTING/REJECTION Sample Clauses

INSPECTION/TESTING/REJECTION a) Except as otherwise agreed in writing, all shipments shall be subject to inspection by Plymouth after receipt by Plymouth at destination. In addition, all material and work in progress shall be subject to inspection and test at all times and places and when practical, during manufacture, as Plymouth may direct. If inspections, and tests, whether preliminary or final are made on Vendor’s premises, Vendor shall furnish without additional charge, all reasonable facilities and assistance for safe and convenient inspections and tests required by the inspectors in the performance of their duty. All inspections and tests shall be performed in such manner as not to unduly delay the work. Plymouth reserves the right to charge and set off to Vendor any additional cost of inspection and tests when articles are not ready at the time of inspection as requested by Plymouth. Inspection and acceptance by Plymouth shall not be conclusive of compliance of the goods with the warranty provisions of this Agreement and Vendor shall remain responsible for all acts necessary to maintain compliance through the Warranty Provisions as set forth in Article 5, (b) Vendor is to work within and inspect to, tolerances and limitations specified on drawings covering the work, and shall make such tests as are specified in the drawings or test specifications, unless deviation there from is authorized in writing by Plymouth. Verbal changes to tolerance revisions are not official and will not provide grounds for a noncompliance with the drawings or specifications, regardless of their source, (c) No substitution of materials or accessories may be made without written permission from Plymouth, and no charges for extras will be allowed unless the same have been ordered in writing by Plymouth and the price and changes mutually agreed upon in writing, (d) Payment by Plymouth for the goods or services delivered hereunder shall not constitute acceptance. Plymouth retains the right to inspect the goods or work performed and to reject any or all of the goods or work performed which in Plymouth’s judgment, fail to comply with the warranty requirements, (d) Goods rejected by Plymouth and goods supplied in excess of quantities called for herein may be returned to Vendor at Vendor’s expense and in addition to Plymouth’s other rights Plymouth may charge Vendor all expenses of unpacking, examining, repacking, and reshipping such goods (e) Vendor shall immediately notify Plymouth of any non- conformance de...
Sample 1
AutoNDA by SimpleDocs
INSPECTION/TESTING/REJECTION. The City shall have the right to inspect all or any part of the Products. If, in the City’s judgment, all or any part of the Products is defective or damaged or fails to conform strictly to the requirements of this Contract, then the City, without limiting its other rights or remedies, may, at its discretion: (i) reject such Products; (ii) require Bidder to correct or replace such Products at Bidder’s cost; (iii) obtain new Products to replace the Products that are defective, damaged, or nonconforming and charge Bidder with any excess cost incurred thereby; and/or (iv) cancel all or any part of any order or this Contract. Products so rejected may be returned or held at Bidder’s expense and risk.
Sample 1Sample 2
INSPECTION/TESTING/REJECTION. Payment for the goods or services delivered hereunder shall not constitute acceptance thereof. Purchaser shall have the right to inspect such goods and to reject any or all of said goods which are in Purchaser’s judgment defective. Goods so rejected and goods supplied in excess of quantities called for herein may be returned to the Supplier at its expense and, in addition to Purchaser’s other rights, Purchaser may charge the Supplier all expenses of unpacking, examining, repacking, and reshipping such goods. In the event Purchaser receives goods whose defects or nonconformities are not apparent on examination resulting in deterioration of its finished product, Purchaser reserves the right to require the replacement, as well as payment of damages. No substitute will be accepted without specific written approval by Purchaser.
Sample 1
INSPECTION/TESTING/REJECTION. All Work shall be received subject to Xxxxx’s right of inspection and rejection. Defective goods or goods not in accordance with Xxxxx’s specifications will be held for Seller’s instructions at Seller’s risk and if Seller so directs, will be returned at Seller’s expense. Payment by Buyer prior to inspection shall not constitute acceptance by Xxxxx and is without prejudice to any and all claims that Xxxxx may have against Seller. Inspection and acceptance do not relieve the Seller of any liability for latent defects.
Sample 1
INSPECTION/TESTING/REJECTION. Owner shall have the right to inspect all or any part of the Work and to reject all or any part of the Work that is, in Owner’s judgment, defective or damaged or that in any way fails to conform strictly to the requirements of this Contract and Owner, without limiting its other rights or remedies, may require correction or replacement at Contractor’s cost, perform or have performed all Work necessary to complete or correct all or any part of the Work that is defective, damaged, or nonconforming and charge Contractor with any excess cost incurred thereby, or cancel all or any part of any order or this Contract. Work so rejected may be returned or held at Contractor’s expense and risk.
Sample 1

Related to INSPECTION/TESTING/REJECTION

  • Inspection/Testing In order to assess Supplier’s work quality and/or compliance with this Order, upon reasonable notice by Buyer: (a) all goods, materials and services related to the items purchased hereunder, including, raw materials, components, assemblies, work in process, tools and end products shall be subject to inspection and testing by Buyer, its customer, representative or regulatory authorities at all places, including sites where the goods are made or located or the services are performed, whether at Supplier’s premises or elsewhere; and (b) all of Supplier’s facilities, books and records relating to this Order shall be subject to inspection by Buyer or its designee. If specific Buyer and/or Buyer’s customer tests, inspection and/or witness points are included in this Order, the goods shall not be shipped without an inspector’s release or a written waiver of test/inspection/witness with respect to each such point; however, Buyer shall not be permitted to unreasonably delay shipment; and Supplier shall notify Buyer in writing at least twenty (20) days prior to each of Supplier’s scheduled final and, if applicable, intermediate test/inspection/witness points. Supplier agrees to cooperate with such/audit inspection including, completing and returning questionnaires and making available its knowledgeable representatives. Buyer’s failure to inspect or test goods, materials or services or Buyer’s failure to reject or detect defects by inspection or testing shall not relieve Supplier from its warranty obligations or any of its other obligations or responsibilities under this Order. Supplier agrees to provide small business as well as minority and/or women owned business utilization and demographic data upon request.

  • Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.

  • Random Testing Notwithstanding any provisions of the Collective Agreement or any special agreements appended thereto, section 4.6 of the Canadian Model will not be applied by agreement. If applied to a worker dispatched by the Union, it will be applied or deemed to be applied unilaterally by the Employer. The Union retains the right to grieve the legality of any imposition of random testing in accordance with the Grievance Procedure set out in this Collective Agreement.

  • Laboratory Testing All laboratories selected by UPS Freight for analyzing Controlled Substances Testing will be HHS certified.

  • Equipment Testing and Inspection 2.1.1 The Interconnection Customer shall test and inspect its Small Generating Facility and Interconnection Facilities prior to interconnection. The Interconnection Customer shall notify the NYISO and the Connecting Transmission Owner of such activities no fewer than five Business Days (or as may be agreed to by the Parties) prior to such testing and inspection. Testing and inspection shall occur on a Business Day. The Connecting Transmission Owner may, at its own expense, send qualified personnel to the Small Generating Facility site to inspect the interconnection and observe the testing. The Interconnection Customer shall provide the NYISO and Connecting Transmission Owner a written test report when such testing and inspection is completed. The Small Generating Facility may not commence parallel operations if the NYISO, in consultation with the Connecting Transmission Owner, finds that the Small Generating Facility has not been installed as agreed upon or may not be operated in a safe and reliable manner. 2.1.2 The NYISO and Connecting Transmission Owner shall each provide the Interconnection Customer written acknowledgment that it has received the Interconnection Customer’s written test report. Such written acknowledgment shall not be deemed to be or construed as any representation, assurance, guarantee, or warranty by the NYISO or Connecting Transmission Owner of the safety, durability, suitability, or reliability of the Small Generating Facility or any associated control, protective, and safety devices owned or controlled by the Interconnection Customer or the quality of power produced by the Small Generating Facility.

  • Inspection and Tests 3.8.1 The Procuring entity or its representative shall have the right to inspect and/or to test the goods to confirm their conformity to the Contract specifications. The Procuring entity shall notify the tenderer in writing in a timely manner, of the identity of any representatives retained for these purposes. 3.8.2 The inspections and tests may be conducted in the premises of the tenderer or its subcontractor(s), at point of delivery, and/or at the Goods’ final destination If conducted on the premises of the tenderer or its subcontractor(s), all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring entity. 3.8.3 Should any inspected or tested goods fail to conform to the Specifications, the Procuring entity may reject the equipment, and the tenderer shall either replace the rejected equipment or make alterations necessary to make specification requirements free of costs to the Procuring entity. 3.8.4 The Procuring entity’s right to inspect, test and where necessary, reject the goods after the Goods’ arrival shall in no way be limited or waived by reason of the equipment having previously been inspected, tested and passed by the Procuring entity or its representative prior to the equipment delivery. 3.8.5 Nothing in paragraph 3.8 shall in any way release the tenderer from any warranty or other obligations under this Contract.

  • Right to Observe Testing Developer and Connecting Transmission Owner shall each notify the other Party, and the NYISO, in advance of its performance of tests of its Attachment Facilities. The other Party, and the NYISO, shall each have the right, at its own expense, to observe such testing.

  • Acceptance Testing At the time of installation of a LIS trunk group, and at no additional charge, acceptance tests will be performed to ensure that the service is operational and meets the applicable technical parameters.

  • Loop Testing/Trouble Reporting 2.1.6.1 Telepak Networks will be responsible for testing and isolating troubles on the Loops. Telepak Networks must test and isolate trouble to the BellSouth portion of a designed/non-designed unbundled Loop (e.g., UVL-SL2, UCL-D, UVL-SL1, UCL-ND, etc.) before reporting repair to the UNE Customer Wholesale Interconnection Network Services (CWINS) Center. Upon request from BellSouth at the time of the trouble report, Telepak Networks will be required to provide the results of the Telepak Networks test which indicate a problem on the BellSouth provided Loop. 2.1.6.2 Once Telepak Networks has isolated a trouble to the BellSouth provided Loop, and had issued a trouble report to BellSouth on the Loop, BellSouth will take the actions necessary to repair the Loop if a trouble actually exists. BellSouth will repair these Loops in the same time frames that BellSouth repairs similarly situated Loops to its End Users. 2.1.6.3 If Telepak Networks reports a trouble on a non-designed or designed Loop and no trouble actually exists, BellSouth will charge Telepak Networks for any dispatching and testing (both inside and outside the CO) required by BellSouth in order to confirm the Loop’s working status. 2.1.6.4 In the event BellSouth must dispatch to the end-user’s location more than once due to incorrect or incomplete information provided by Telepak Networks (e.g., incomplete address, incorrect contact name/number, etc.), BellSouth will xxxx Xxxxxxx Networks for each additional dispatch required to repair the circuit due to the incorrect/incomplete information provided. BellSouth will assess the applicable Trouble Determination rates from BellSouth’s FCC or state tariffs.

  • ODUF Testing 6.6.1 Upon request from TWTC, AT&T shall send ODUF test files to TWTC. The Parties agree to review and discuss the ODUF file content and/or format. For testing of usage results, AT&T shall request that TWTC set up a production (live) file. The live test may consist of TWTC’s employees making test calls for the types of services TWTC requests on ODUF. These test calls are logged by TWTC, and the logs are provided to AT&T. These logs will be used to verify the files. Testing will be completed within thirty (30) days from the date on which the initial test file was sent.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!