TEMPORARY POWER. LICENSEE shall be permitted at any time during the Term of each Supplement, to install, maintain and/or provide access to and use of, as necessary (during any power interruption at the Premises), a temporary power source, and all related equipment and appurtenances within the Premises, or elsewhere on the Property in such locations as reasonably approved by LICENSOR. LICENSEE shall be permitted to connect the temporary power source to its equipment on the Premises in areas and manner approved by LICENSOR.
TEMPORARY POWER. The Contractor shall be responsible for the cost of temporary power used during the construction of the Project, including, but not limited to, the cost of installing such temporary wiring as may be required to bring power to the site. The Contractor shall also be responsible for the cost of all temporary construction necessary on the site.
TEMPORARY POWER. The Construction Manager shall be responsible for the cost of temporary power used during the construction of the Project, including, but not limited to, the cost of installing such temporary wiring as may be required to bring power to the site. The Construction Manager shall also be responsible for the cost of all temporary construction necessary on the site.
TEMPORARY POWER. DPA/OSA through its code review agent is authorized to give permission to temporarily supply and use power in part of an electric installation before such installation has been fully completed and the final certificate of completion has been issued. The part covered by the temporary certificate shall comply with the requirements specified for temporary lighting, heat or power in NFPA 70. 109.1 Payment of fees. Refer to DPA/OSA Building Code Compliance Policy.
TEMPORARY POWER. Temporary power 15- and 20-amp service shall be protected by Ground Fault Circuit Interrupters (GFCI). Temporary power cords shall be heavy-duty construction grade. Cords less than #14 AWG will not be allowed on site. CONTROLLING ENERGY HAZARDS - LOCKOUT/TAGOUT (LOTO). Any applicable Swinerton policies or operating procedures apply in addition to the standards applicable to the control of energy during servicing and/or maintenance, and/or start-up of machines, equipment, and circuits. Any applicable Swinerton policies or operating procedures also apply to servicing and/or maintenance during normal production operations under any of the following circumstances: If a worker is required to remove or bypass a guard or other safety device; or If a worker is required to place any part of his or her body into an area on a machine or piece of equipment: where work is actually performed upon the material being processed; or where an associated danger zone exists during a machine operating cycle; or During the start-up, pressurization and/or energization of onsite utilities.
TEMPORARY POWER. The Construction Manager shall be responsible for the cost of temporary power used during the construction of the Project, including, but not limited to, the cost of installing such temporary wiring as may be required to bring power to the site. The Construction Manager shall also be responsible for the cost of all temporary construction necessary on the site. Workhours, Site Office, and Coordination with Client Agency and Community Workhours. The Construction Manager shall comply with the Noise Ordinance and neither it nor its subcontractors shall undertake work on the Project site other than at the times and sound level permitted by the Noise Ordinance.
TEMPORARY POWER. Subcontractor to provide its own power (i.e. generator) and to include all associated standby trades for its own operations.
TEMPORARY POWER. Landlord shall furnish to Tenant, at Landlord's sole cost and expense, temporary electrical power and free access to service elevators at all times during Tenant's construction of the Tenant Improvements (including during business hours, after-hours and on weekends).
TEMPORARY POWER. Temporary power will be provided to the jobsite by Contractor. Distribution will also be provided by Contractor. Subcontractor shall be responsible for distribution of power from that point.
TEMPORARY POWER. The Contractor shall at its expense provide all temporary power and/or artificial lighting required for the execution of the Works. The Contractor shall further allow at its expense all use of temporary installed power and artificial lighting necessary for the execution of such works by specialty contractors directly engaged by the Owner that normally take place on the building site, to the judgment of the Engineer. The Contractor shall provide and maintain all temporary cables and wiring, shall pay all fees and charges, and shall arrange for clearing it away at completion of the Works of all temporary provisions, all of this at the Contractor’s expense, and in all cases for the Contractor, its sub-contractors, and any specialty contractors. All works for temporary power supply shall be executed in a safe and workmanlike manner, to the approval of the Engineer and the Provincial Electricity Authority (PEA), as applicable. For the purpose of system testing of the air-conditioning, electrical and lifts installations, the Contractor shall arrange for an electrical main supply connection of sufficient capacity. The cost for this connection and the charges for consumption of electricity shall be paid by the Contractor. The costs for connection of permanent power supply to the building will be paid by the Owner and are not included in the Contract. All consumption-charges for electricity from the date of commencement until the date of Practical Completion of the Works will be at the expense of, and paid for by, the Contractor.
