LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL Sample Clauses

LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. The Board of Directors will promulgate and regularly update procedures for length of time for aid and assistance; renewability; recall through the Illinois Public Works Mutual Aid Network (IPWMAN)
AutoNDA by SimpleDocs
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. Unless otherwise provided, the duration of Provider's assistance shall be for an initial period of seven days, starting from the time of arrival. Thereafter, assistance may be extended in daily or weekly increments as the situation warrants, for a period agreed upon by the authorized representatives of Provider and Recipient. As noted in Section II of this Agreement, Provider's personnel, equipment, and other resources shall remain subject to recall by Provider to provide for its own citizens if circumstances so warrant. Provider shall make a good faith effort to provide at least twenty-four (24) hours advance notification to Recipient of its (Provider's) intent to terminate mission, unless such notice is not practicable, in which case as much notice as is reasonable under the circumstances shall be provided.
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. Unless otherwise provided, the duration of Xxxxxxxx's assistance shall be for an initial period of seven days, starting from the time of arrival. Thereafter, assistance may be extended in daily or weekly increments as the situation warrants, for a period agreed upon by the authorized representatives of Provider and Recipient. As noted in Section II of this Agreement, Provider's personnel, equipment, and other resources shall remain subject to recall by Provider to provide for its own citizens if circumstances so warrant. Provider shall make a good faith effort to provide at least twenty-four (24) hours advance notification to Recipient of Provider's intent to terminate mission, unless such notice is not practicable, in which case as much notice as is reasonable under the circumstances shall be provided.
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. A. Unless otherwise provided, the duration of Provider's aid and assistance shall be presumed to be for an initial period of twelve (12) hours. Thereafter, assistance may be extended as the situation warrants for periods agreed upon by the authorized representatives of Provider and Recipient. The twenty-four hour period and any other agreed upon time periods shall start when the aid and assistance departs from Provider’s location with the intent of going to Recipient’s location. The aid and assistance shall end when the aid and assistance returns to Provider’s location and no further expectation of aid and assistance exists between Provider and Recipient. B. In accordance with Section II of this Agreement, Provider's aid and assistance shall remain subject to recall by Provider to provide for its own citizens if circumstances so warrant. Provider shall make a good faith effort to provide at least twenty-four (24) hours advance notification to Recipient of Provider's intent to terminate portions of or all aid and assistance, unless such notice is not practicable, in which case as much notice as is reasonable under the circumstances shall be provided.
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. It is presumed that a provider’s aid and assistance shall be given for an initial period of twelve (12) hours. Thereafter, assistance shall be extended as the provider and recipient shall agree. The twelve
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. A. Unless otherwise provided, the duration of Provider's assistance shall be presumed to be for an initial period of twenty-four (24) hours, starting from the time of arrival. Thereafter, assistance may be extended as the situation warrants for periods agreed upon by the authorized representatives of Provider and Recipient. B. As noted in Section II of this Agreement, Provider's personnel, equipment, and other resources shall remain subject to recall by Provider to provide for its own citizens if circumstances so warrant. Provider shall make a good faith effort to provide at least twenty-four
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL. A. The duration of Provider’s assistance shall be for the period requested, starting from the time of arrival. Thereafter, assistance may be extended as the situation warrants for periods agreed upon by the authorized representatives of Provider and Recipient. B. As noted in Section II of this Agreement, Provider’s personnel, equipment, and other resources shall remain subject to recall by Provider to provide for its own citizens if circumstances so warrant. Provider shall make a good faith effort to provide at least twenty-four (24) hours advance notification to Recipient of its (Provider’s) intent to terminate portions or all assistance, unless such notice is not practicable, in which case as much notice as is reasonable under the circumstances shall be provided.
AutoNDA by SimpleDocs
LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL demobilization 1. Unless otherwise mutually agreed to in writing, the duration of a Provider’s aid and assistance shall be for an initial period of seven (7) days, beginning from the date the Provider’s aid and assistance commences at the stricken site. Thereafter, aid and assistance may be extended in daily or weekly increments as the situation warrants, for a period mutually agreed upon. 2. The Provider's personnel, equipment, and other resources shall remain subject to recall by the Provider to provide aid and assistance to persons within its jurisdictional boundaries if circumstances so warrant. The Provider shall make a good faith effort to give at least twenty- four (24) hours advance written notice to the Recipient of the Provider's intent to recall its aid and assistance. If such notice is not practicable, the Provider shall give the Recipient as much advance written notice as is reasonable under the circumstances. 3. After the mutually agreed upon time, the Provider’s aid and assistance will demobilize. Coordination and demobilization process will follow the current demobilization policies and procedures as defined by the Provider and Recipient.

Related to LENGTH OF TIME FOR AID AND ASSISTANCE; RENEWABILITY; RECALL

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • Extension of Time; Waiver At any time prior to the Effective Time, the parties may, by action taken or authorized by their respective Boards of Directors, to the extent permitted by applicable Law, (a) extend the time for the performance of any of the obligations or acts of the other parties, (b) waive any inaccuracies in the representations and warranties of the other parties set forth in this Agreement or any document delivered pursuant hereto or (c) subject to applicable Law, waive compliance with any of the agreements or conditions of the other parties contained herein; provided, however, that after the Company Stockholder Approval has been obtained, no waiver may be made that pursuant to applicable Law requires further approval or adoption by the Stockholders without such further approval or adoption. Any agreement on the part of a party to any such waiver shall be valid only if set forth in a written instrument executed and delivered by a duly authorized officer on behalf of such party. No failure or delay of any party in exercising any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, or any course of conduct, preclude any other or further exercise thereof or the exercise of any other right or power. The rights and remedies of the parties hereunder are cumulative and are not exclusive of any rights or remedies which they would otherwise have hereunder.

  • Extension of Time, Waiver, Etc At any time prior to the Effective Time, any party may, subject to applicable Law, (a) waive any inaccuracies in the representations and warranties of any other party hereto, (b) extend the time for the performance of any of the obligations or acts of any other party hereto or (c) waive compliance by the other party with any of the agreements contained herein or, except as otherwise provided herein, waive any of such party’s conditions. Notwithstanding the foregoing, no failure or delay by the Company, Parent or Merger Sub in exercising any right hereunder shall operate as a waiver thereof nor shall any single or partial exercise thereof preclude any other or further exercise thereof or the exercise of any other right hereunder. Any agreement on the part of a party hereto to any such extension or waiver shall be valid only if set forth in an instrument in writing signed on behalf of such party.

  • COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.

  • Public Posting of Approved Users’ Research Use Statement The PI agrees that information about themselves and the approved research use will be posted publicly on the dbGaP website. The information includes the PI’s name and Requester, project name, Research Use Statement, and a Non-Technical Summary of the Research Use Statement. In addition, and if applicable, this information may include the Cloud Computing Use Statement and name of the CSP or PCS. Citations of publications resulting from the use of controlled-access datasets obtained through this DAR may also be posted on the dbGaP website.

  • Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Amending of Time Limits The time limits fixed in both the grievance and arbitration procedure may be extended by consent of the parties.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!