Limits of Liability To the fullest extent permitted by applicable law, (1) You agree that We and HomeServe, and both of our respective parents, successors, affiliates, approved technicians and Our and their officers, directors, employees, affiliates, agents, contractors or similar parties acting on behalf of either Us or HomeServe shall not be liable to You or anyone else for: (a) any actual losses or direct damages that exceed the lowest applicable per repair Benefit Limit, or, if there is no maximum Benefit Limit, any actual losses or direct damages that exceed the cost of repairs provided for in the “What is a Covered Repair?” section(s) of this Service Agreement, relating to any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided hereunder giving rise to such loss or damage; or (b) any amount of any form of indirect, special, punitive, incidental or consequential losses or damages, damages based on anticipated or lost profits, wages, or revenue, or damages based on diminution in value or a multiple of earnings, including those caused by any fault, failure, delay or defect in providing any repairs performed by Us, HomeServe or on behalf of either Us or HomeServe or services provided under this Service Agreement, regardless of whether such damages were foreseeable and whether or not We or HomeServe or anyone acting on behalf of either Us or HomeServe have been advised of the possibility of such damages (the damages listed in clauses (a) and (b), collectively the “Excluded Damages”); and (2) these limitations and waivers shall apply to all claims and all liabilities and shall survive the cancellation or expiration of this Service Agreement. You may have other rights that vary from state to state. Arbitration: YOU, NHRW AND HOMESERVE ALL AGREE TO RESOLVE DISPUTES BY BINDING ARBITRATION as follows:
Aggregate Limits of Liability The basic coverage limits of liability may be subject to annual aggregate limits. If this is the case the annual aggregate limits of liability must be at least two (2) times the limits required for each policy, or the aggregate may equal the limits required but must apply separately to this Agreement.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Risks and Limits of Liability Contractor shall maintain the following insurance coverages in the following amounts:
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
