Service Level Agreement 6.1 NCR Voyix will use commercially reasonable efforts to make the Service available to you at or above the Availability Rate set forth at xxxxx://xxx.xxx.xxx/support/aloha-sla. If NCR Voyix does not meet the Availability Rate, you are entitled to request a service-level credit subject to the terms of this Agreement. This credit is calculated as a percentage of the monthly recurring bill (or monthly pro rata share of billing, if billing does not occur monthly) for the Service for the month in which the Availability Rate was not met. The Availability Rate is determined by: (a) dividing the total number of valid outage minutes in a calendar month by the total number of minutes in that month; (b) subtracting that quotient from 1.00; (c) multiplying that difference by 100; and (d) rounding that result to two decimal places in accordance with standard rounding conventions. The number of outage minutes per day for a given service is determined by the lesser of the number of outage minutes.
6.2 Unavailability due to other conditions or caused by factors outside of NCR Voyix’s reasonable control will not be included in the calculation of the Availability Rate. Further, the following are expressly excluded from the calculation of the Availability Rate: (a) service unavailability affecting services or application program interfaces that are not used by you; (b) cases where fail-over to another data center is available but not utilized; (c) transient time-outs, required re-tries, or slower-than-normal response caused by factors outside of NCR Voyix’s reasonable control; (d) Scheduled Downtime, including maintenance and upgrades; (e) force majeure; (f) transmission or communications outages outside the NCR Voyix- controlled environment; (g) store-level down-time caused by factors outside of NCR Voyix’s reasonable control; (h) outages attributable to services, hardware, or software not provided by NCR Voyix, including, but not limited to, issues resulting from inadequate bandwidth or related to third-party software or services;
(i) use of the Service in a manner inconsistent with the documentation for the application program interface or the NCR Voyix Product; (j) your Point of Sale (“POS”) failure or the failure to properly maintain the POS environment, including updating the POS firmware or version of the software running on the POS as recommended by either NCR Voyix, a third-party POS reseller or servicer; and (k) issues related to third party domain name system (“DNS”) errors or failures.
6.3 To obtain a service-level credit, you must submit a claim by contacting NCR Voyix through the website at xxxxx://xxx.xxx.xxx/support/aloha-sla Your failure to provide the claim and other information will disqualify you from receiving a credit. NCR Voyix must receive claims within 60 days from the last day of the impacted month. After that date, claims are considered waived and will be refused. You must be in compliance with the Agreement in order to be eligible for a service-level credit. You may not unilaterally offset for any performance or availability issues any amount owed to NCR Voyix. If multiple Services experience an outage in a given month, the total credit for that month will be the highest credit allowed for any single Service which failed; there is no stacking of credits.
6.4 The remedies set forth in the Section are your sole and exclusive remedies for performance or availability issues affecting the Services, including any failure by NCR Voyix to achieve the Availability Rate.
Service Level Agreements If a Service or a Plan includes a Service Level Agreement (SLA):
(a) we are liable for any remedy or rebate specified by the SLA; and
(b) subject to clauses 40 to 42, and to the express terms of the SLA, our liability for breach of the SLA is limited to such remedy or rebate.
Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.
Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor.
12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby.
13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition.
13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and
13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph
13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State.
13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal.
13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the
Proposed Policies and Procedures Regarding New Online Content and Functionality By October 31, 2017, the School will submit to OCR for its review and approval proposed policies and procedures (“the Plan for New Content”) to ensure that all new, newly-added, or modified online content and functionality will be accessible to people with disabilities as measured by conformance to the Benchmarks for Measuring Accessibility set forth above, except where doing so would impose a fundamental alteration or undue burden.
a) When fundamental alteration or undue burden defenses apply, the Plan for New Content will require the School to provide equally effective alternative access. The Plan for New Content will require the School, in providing equally effective alternate access, to take any actions that do not result in a fundamental alteration or undue financial and administrative burdens, but nevertheless ensure that, to the maximum extent possible, individuals with disabilities receive the same benefits or services as their nondisabled peers. To provide equally effective alternate access, alternates are not required to produce the identical result or level of achievement for persons with and without disabilities, but must afford persons with disabilities equal opportunity to obtain the same result, to gain the same benefit, or to reach the same level of achievement, in the most integrated setting appropriate to the person’s needs.
b) The Plan for New Content must include sufficient quality assurance procedures, backed by adequate personnel and financial resources, for full implementation. This provision also applies to the School’s online content and functionality developed by, maintained by, or offered through a third-party vendor or by using open sources.
c) Within thirty (30) days of receiving OCR’s approval of the Plan for New Content, the School will officially adopt, and fully implement the amended policies and procedures.
COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.
Continuation of Work Pending the resolution of any dispute or claim pursuant to this Article 11, the Parties agree that performance of all obligations will be pursued diligently.
