Management of the Trust The business and affairs of the Trust shall be managed by or under the direction of the Trustees, and they shall have all powers necessary or desirable to carry out that responsibility. The Trustees may execute all instruments and take all action they deem necessary or desirable to promote the interests of the Trust. Any determination made by the Trustees in good faith as to what is in the interests of the Trust shall be conclusive. In construing the provisions of this Declaration, the presumption shall be in favor of a grant of power to the Trustees.
Management of the Company The Company's business and affairs shall be conducted and managed by the Member(s) in accordance with this Agreement and the laws of the State of the Formation. Single-Member (Applies ONLY if Single-Member): The Member(s) of the Company has sole authority and power to act for or on behalf of the Company, to do any act that would be binding on the Company or incur any expenditures on behalf of the Company. The Member(s) shall not be liable for the debts, obligations, or liabilities of the Company, including under a judgment, decree, or order of a court. The Company is organized as a “member-managed” limited liability company. The Member(s) is designated as the initial managing Member(s). Multi-Member (Applies ONLY if Multi-Member): Except as expressly provided elsewhere in this Agreement, all decisions respecting the management, operation, and control of the business and affairs of the Company and all determinations made in accordance with this Agreement shall be made by the affirmative vote or consent of Member(s) holding a majority of the Members’ Percentage Interests. Notwithstanding any other provision of this Agreement, the Member shall not, without the prior written consent of the unanimous vote or consent of the Member(s), sell, exchange, lease, assign or otherwise transfer all or substantially all of the assets of the Company; sell, exchange, lease (other than space leases in the ordinary course of business), assign or transfer the Company’s assets; mortgage, pledge or encumber the Company’s assets other than is expressly authorized by this Agreement; prepay, refinance, modify, extend or consolidate any existing mortgages or encumbrances; borrow money on behalf of the Company; lend any Company funds or other assets to any person or entity; establish any reserves for working capital repairs, replacements, improvements or any other purpose; confess a judgment against the Company; settle, compromise or release, discharge or pay any claim, demand or debt, including claims for insurance; approve a merger or consolidation of the Company with or into any other limited liability company, corporation, partnership or other entity; or change the nature or character of the business of the Company. The Member(s) shall receive such sums for compensation as Member(s) of the Company as may be determined from time to time by the affirmative vote or consent of Member(s) holding a majority of the Member(s)’ Percentage Interests.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Management of Company 5.1.1 The Members, within the authority granted by the Act and the terms of this Agreement shall have the complete power and authority to manage and operate the Company and make all decisions affecting its business and affairs.
5.1.2 Except as otherwise provided in this Agreement, all decisions and documents relating to the management and operation of the Company shall be made and executed by a Majority in Interest of the Members.
5.1.3 Third parties dealing with the Company shall be entitled to rely conclusively upon the power and authority of a Majority in Interest of the Members to manage and operate the business and affairs of the Company.
