NOTICE TO THE GOVERNMENT OF DELAYS Sample Clauses

NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or completion date, or as soon as the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the OCO and the TO COR, in writing. This notification shall give pertinent details, but this data shall be informational only in character; this term shall not be construed as a waiver by the Government of any delivery schedule or date, or any rights or remedies provided by law or under this contract.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the COTR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.
Sample 1Sample 2See All (5)
NOTICE TO THE GOVERNMENT OF DELAYS. (a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. (b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. (c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor.
Sample 1
NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or completion date, or as soon as the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the TOCO and the Task Order Contracting Officer Representative (TO COR), in writing. This notification shall give pertinent details, but this data shall be informational only in character; this term shall not be construed as a waiver by the Government of any delivery schedule or date, or any rights or remedies provided by law or under this contract. (a) The following is a schedule of all deliverables, including administrative deliverables, required during the period of performance of this contract: Item Description Qty Due Dates Deliver to Reference 1 Monthly Contract Status Report 1 15th calendar day of each month as specified in F.6.1. - IDIQ CO - IDIQ COR Section F.6.1 2 Monthly Task Order Status Report 1 15th calendar day of each month, or as specified in the individual task orders as specified in F.6.2. - IDIQ CO - TOCO - TO COR Section F.6.2 (b) All applicable task order deliverables and their required delivery dates, destination of delivery, and schedule for completion of work to be performed, will be specified in task orders issued under this contract, as applicable. (c) For purposes of delivery, all deliverables shall be made by close of business (COB) 4:30 P.M. local time at destination, Monday through Friday, unless stated otherwise in the task order. (d) All deliverables submitted in electronic format shall be free of any known computer virus or defects. If a virus or defect is found, the initial deliverable will not be accepted. A replacement file shall be provided within two business days after notification. (e) Any failure of the Contractor to adhere to a delivery schedule or a deliverable requirement may be reflected in the Contractor’s past performance report.
Sample 1
NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the delivery schedule(s) or date(s), or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this BPA, the Contractor shall immediately notify the CO and the COR, in writing, giving pertinent details, provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by CBP of any delivery schedule or date or of any rights or remedies provided by law or under this BPA.
Sample 1

Related to NOTICE TO THE GOVERNMENT OF DELAYS

  • Notification of Government Investigation or Legal Proceeding Provider shall notify OIG, in writing, of any ongoing investigation or legal proceeding by a governmental entity or its agents involving an allegation that Provider has committed a crime or has engaged in fraudulent activities, within 30 days of Provider receiving notice of such investigation or legal proceeding. This notification shall include a description of the allegation(s), the identity of the investigating or prosecuting agency, and the status of such investigation or legal proceeding. Within 30 days after resolution of the matter, Provider shall notify OIG, in writing, of the resolution of the investigation or legal proceeding.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Optional Xactimate Response Attachment (Part 2)

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • Publication of Notices Any obligation the Agents may have to publish a notice to Holders of Global Notes on behalf of the Issuer will be met upon delivery of the notice to DTC.

  • Agreement Subject to CAISO Tariff The Parties will comply with all applicable provisions of the CAISO Tariff. This Agreement shall be subject to the CAISO Tariff, which shall be deemed to be incorporated herein.

  • Notice of Special Matters The Corporation covenants with the Warrant Agent that, so long as any Warrant remains outstanding, it will give notice to the Warrant Agent and to the Registered Warrantholders of its intention to fix a record date that is prior to the Expiry Date for any matter for which an adjustment may be required pursuant to Section 4.1. Such notice shall specify the particulars of such event and the record date for such event, provided that the Corporation shall only be required to specify in the notice such particulars of the event as shall have been fixed and determined on the date on which the notice is given. The notice shall be given in each case not less than 14 days prior to such applicable record date. If notice has been given and the adjustment is not then determinable, the Corporation shall promptly, after the adjustment is determinable, file with the Warrant Agent a computation of the adjustment and give notice to the Registered Warrantholders of such adjustment computation.

  • Auction Schedule; Method of Submission of Orders (a) The Funds and the Auction Agent shall conduct Auctions for each series of Preferred Shares in accordance with the schedule set forth below. Such schedule may be changed at any time by the Auction Agent with the consent of the Fund, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to BD. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Funds and the Broker-Dealers of the Maximum Rate as set forth in Section 3.2(a) hereof.

  • Additional Wet Weather Procedure 14.15.1 Remaining On Site a) for more than an accumulated total of four hours of ordinary time in any one day; or b) after the meal break, as provided for in clause 17.1 of the Award, for more than an accumulated total of 50% of the normal afternoon work time; or c) during the final two hours of the normal work day for more than an accumulated total of one hour, the Enterprise will not be entitled to require the employees to remain on site beyond the expiration of any of the above circumstances.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!