Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A) Environmental Management Plan: Site Management Plan: Commissioning and Handover Plan: Work Health and Safety Plan: ESD and WOL Plan: Other: [SPECIFY] Number of days for review of Project Plans: (Clause 9.2(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect or completion of a Variation to overcome a Defect: (Clause 9.11) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ PAYMENT Times for submission of payment claims by the Contractor to the Contract Administrator: (Clause 12.2(a)) Monthly on the ………….................... day of each month Number of business days for payment: (Clause 12.5) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate: (Clause 12.13) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ........................
Number of days for submission of Project Plans. (Clause 7.4(a)(ii)(A)) Site Management Plan: .................................................................
Number of days for submission of Project Plans. (Clause 7.4(a)(ii)A) Site Management Plan: ……………………………… Environmental Management Plan: ……………………………… Work Health and Safety Plan ……………………………… Commissioning and Handover Plan: ……………………………… Other [SPECIFY]: ……………………………… Number of days for review of Project Plans: (Clause 7.4(a)(ii)B) ....................................................................................................... CLAUSE 8 – TIME Maximum intervals between program updates by Consultant: (Clause 8.2(b)) ....................................................................................................... Program format to be compatible with: (Clause 8.2(d)) [Primavera Suretrak/Microsoft Project] or approved equivalent CLAUSE 10 - PAYMENT Times for submission of payment claims by the Consultant to Contractor's Representative: (Clause 10.2(a)) Monthly on the ………….. day of each month OR Completion of the following Milestones: .......................................................................................................
Number of days for submission of Project Plans. (Clause 7.4(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other [SPECIFY]: days Number of days for review of Project Plans: (Clause 7.4(a)(ii)B) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other [SPECIFY]: days CLAUSE 8 - TIME Maximum intervals between program updates by Subconsultant: (Clause 8.2(b)(ii)) Program format to be compatible with: (Clause 8.2(b)(v)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent
Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A) Environmental Management Plan: Site Management Plan: Commissioning and Handover Plan: Work Health and Safety Plan: Other: [SPECIFY] Number of days for review of Project Plans: (Clause 9.2(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect or completion of a Variation to overcome a Defect: (Clause 9.11) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ PAYMENT Times for submission of payment claims for the Incentive (if any) by the Contractor to the Contract Administrator: (Clauses 12.1(d) and 18.4(a)) ........................................................................................... Times for submission of payment claims by the Contractor to the Contract Administrator: (Clause 12.2(a)) Monthly, on the ............... day of each month Number of business days for payment: (Clause 12.5) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate: (Clause 12.13) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: the rate in paragraph (1); and the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia:
Number of days for submission of Project Plans. (Clause 8.7(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 8.7(a)(ii)B) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days CLAUSE 9 - TIME Maximum intervals between program updates by Subcontractor: (Clause 9.2(b)(ii)) Program format to be compatible with: (Clause 9.2(b)(iv)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent
Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A) Environmental Management Plan: days Fraud and Corruption Control Plan: days Local Industry Capability Plan: days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B) Environmental Management Plan: days Fraud and Corruption Control Plan: days Local Industry Capability Plan: days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days Period by which Defects Liability Period will be extended following rectification of a Defect or Completion of a Variation to overcome a Defect: (Clause 9.11) Defects Records and Reports (additional): (Clause 9.15(b)(vi)) CLAUSE 10 - TIME Maximum intervals between program updates by Contractor: (Clause 10.2(a)(ii)) Program methodology and format: (Clause 10.2(a)(iv)) Prepared as a computerised "Critical Path Method" network precedence diagram, and compatible with Microsoft Project (or equivalent format approved by the Contract Administrator)
Number of days for submission of Project Plans. (Clause 8.7(a)(ii)A) Commissioning and Handover Plan: …………………. days Environmental Management Plan: …………………. days ESD and WOL Plan: …………………. days Quality Plan: …………………. days Site Management Plan: …………………. days Work Health and Safety Plan: …………………. days Other: [SPECIFY] …………………. days Number of days for review of Project Plans: (Clause 8.7(a)(ii)B) Commissioning and Handover Plan: …………………. days Environmental Management Plan: …………………. days ESD and WOL Plan: …………………. days Quality Plan: …………………. days Site Management Plan: …………………. days Work Health and Safety Plan: …………………. days Other: [SPECIFY] …………………. days CLAUSE 9 - TIME Time within which Subcontractor must prepare its program: (Clause 9.2(b)) .....................................................................................................
