Other Contractors and Vendors. PDSC may undertake or award other contracts for additional or related work. Contractor shall cooperate with PDSC and the courts to coordinate appointment procedures and other court activities necessary for efficient and effective administration of this and other contracts for public defense services. Contractor shall reasonably assist non-attorney vendors in billing for services provided at Contractor's request.
Other Contractors and Vendors. SCA may undertake or award other contracts for additional or related work. Contractor shall cooperate with SCA and the courts to coordinate appointment procedures and other court activities necessary for efficient and effective administration of this and other contracts for indigent defense services. Contractor shall reasonably assist nonattorney vendors in billing for services provided at Contractor's request, including providing to the vendor a fee statement/ certification form with all information completed and copies of court orders preauthorizing the services.
Other Contractors and Vendors. Customer must coordinate the work and activities of its own, and its other separate contractors' or vendors', forces in connection with other aspects of the Services being performed by GPC and must cooperate with GPC as reasonably necessary for GPC to carry out its Agreement duties and obligations. If Customer enters into a separate contract directly with any entity other than GPC for the performance of any work related to GPC’s Agreement performance, Customer must coordinate that work with GPC’s performance in such a way that the separate entity's work does not interfere with, hinder, or delay GPC’s performance. If the separate entity's work does interfere with, delay, or make more costly GPC’s performance, GPC will be entitled to an equitable adjustment in the Contract Price and an extension of time for performance.
