Owner’s Right to Carry Sample Clauses

Owner’s Right to Carry. Out the Work
Sample 1Sample 2Sample 3See All (59)
AutoNDA by SimpleDocs
Owner’s Right to Carry. OUT THE WORK If the Contractor defaults or persistently fails or neglects to carry out the Work in accordance with the Contract Documents, or fails to perform a provision of the Contract, the Owner, after 10 days' written notice to the Contractor and without prejudice to any other remedy the Owner may have, may make good such deficiencies and may deduct the reasonable cost thereof, including Owner's expenses and compensation for the Architect's services made necessary thereby, from the payment then or thereafter due the Contractor.
Sample 1
Owner’s Right to Carry. Out the Work. If the Contractor should fail to prosecute, in whole or in part, the Work properly (including the failure to man the job due to labor disputes of any type) or fail to perform any provision of the Contract Documents (including unauthorized schedule delay) the Owner may, without prejudice to any other rights or remedies available to the Owner, give to Contractor seven (7) days prior notice which will specify the Owner's deficiencies. If the Contractor fails or refuses to have such deficiencies made good by others, then at the sole expense of the Contractor, the Owner may deduct the costs thereof from any payments then or thereafter due to the Contractor.
Sample 1
Owner’s Right to Carry. OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten-day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner's expenses and compensation for the Architect's additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Sample 1
Owner’s Right to Carry. Out the Work. If Contractor defaults under any of its material obligations under this Agreement and does not cure that default within 10 Days after Owner gives Contractor written notice of default, Owner shall have the right, in addition to any other remedy it may have, to cure the default at Contractor's expense: provided that if Contractor commences and diligently, proceeds to cure the default during the ten-Day period and actually cures that default within a reasonable time after it receives Owner's notice, Owner shall not exercise its rights under this Section 18.5 as to that default. Owner shall be entitled (subject to Owner's obligation to mitigate its damages) to charge Contractor for all expenses Owner incurs in curing the default or to deduct those expenses from payments Owner otherwise owes or comes to owe Contractor. Owner's exercising any of its rights under this Section 18.5 shall not relieve Contractor of any of its obligations under this Agreement.
Sample 1
Owner’s Right to Carry. OUT THE WORK 2.5.1 If the Design-Builder defaults or neglects to carry out the Work in accordance with the Design-Build Documents and Construction Documents and fails within a seven-day period after receipt of written notice from the ARTICLE A.3 DESIGN-BUILDER
Sample 1
Owner’s Right to Carry. Out the Work § 7.9.1 If the Design-Builder defaults or neglects to carry out the Work in accordance with the Design-Build Documents and fails within a ten (10) Day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Design-Builder the reasonable cost of correcting such Design-Bu sufficient hereunder deficiencies, including, without limitation, Owner’s expenses and compensation for the additional services of Owner Consultants made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the ilder shall be reasonable and necessary. If payments then or thereafter due the Design-Builder are not to cover such amounts, the Design-Builder shall pay the difference to the Owner. The rights of the Owner shall not give rise to any duty on the part of the Owner to exercise same for the benefit of the Design-Builder or any other person or entity. If providing the above-referenced prior notice to the Design-Builder is not reasonable because of emergency or exigent circumstances, the Owner shall provide only such prior notice that is reasonable under the circumstances. § 7.9.2 After the Work is complete, the Owner may make emergency repairs to the Work if necessary to prevent further damage, or if the Design-Builder does not promptly respond to a notice of a condition requiring repairs. Design-Builder shall be responsible to Owner for this cost if the reason for the repairs is defects in the Work. If payments then or thereafter due the Design-Builder are not sufficient to cover such costs, the Design-Builder shall pay the difference to the Owner.
Sample 1
AutoNDA by SimpleDocs

Related to Owner’s Right to Carry

  • OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.

  • STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

  • Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice (which shall be prior written notice except in the event of a circumstance which Landlord in good faith believes to be an emergency) and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term or during any period that Tenant is in monetary or material non-monetary default beyond the applicable cure period, if any, expressly set forth in this Lease, tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so after the expiration of any applicable notice and cure period expressly set forth in this Lease. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Common Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Common Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least ten (10) days’ prior written notice of any work to be performed on the Leased Premises, as well as notice within one (1) day after the commencement of such work); and (iii) supplying any services to be provided by Landlord. Landlord shall also have the right, upon reasonable advance notice to Tenant, to access the Building’s vertical risers and the interstitial space above Tenant’s acoustical ceiling to connect new utility and communications lines from other floors to the base Building utility lines; all of such work shall be done after hours or on weekends. Any entry into the Leased Premises or the Common Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof. Landlord shall conduct all of Landlord’s activities on the Leased Premises during such period of entry in a manner designed to cause minimal interference to Tenant and Tenant’s use of the Leased Premises.

  • Borrower’s Right to Cure (a) Notwithstanding anything to the contrary contained in Section 8.01, in the event of any Event of Default under any covenant set forth in Section 7.11 and until the expiration of the tenth (10th) day after the date on which financial statements are required to be delivered with respect to the applicable fiscal quarter hereunder, the Borrower may engage in a Permitted Equity Issuance to any of the Equity Investors and apply the amount of the Net Cash Proceeds thereof (the “Cure Amount”) to increase Consolidated EBITDA with respect to such applicable quarter; provided that such Net Cash Proceeds (i) are actually received by the Borrower during such fiscal period or after the last day of the fiscal period covered by such financial statements but no later than fifteen (15) days after the date on which financial statements are required to be delivered with respect to such fiscal quarter hereunder, (ii) are Not Otherwise Applied and (iii) do not exceed the aggregate amount necessary to cure such Event of Default under Section 7.11 for any applicable period. The Cure Amount used to calculate Consolidated EBITDA for one fiscal quarter shall be used and included when calculating Consolidated EBITDA for each Test Period that includes such fiscal quarter. The parties hereby acknowledge that this Section 8.05(a) may not be relied on for purposes of calculating any financial ratios other than as applicable to Section 7.11 and shall not result in any adjustment to any amounts other than the amount of the Consolidated EBITDA referred to in the immediately preceding sentence. (b) In each period of four fiscal quarters, there shall be at least two (2) fiscal quarters in which no cure set forth in Section 8.05(a) is made. (c) For the avoidance of doubt, the subsequent performance or observance of any term, covenant or agreement under Section 6.01, 6.02, 6.11 and 6.13 shall cure any Default in respect thereof under Section 8.01(c) notwithstanding that such performance or observance occurred beyond the time or period specified therefor in such Section and such Default shall thereupon be deemed cured and no longer existing or continuing unless the Loans shall have been accelerated and/or the Commitments terminated pursuant to Section 8.02(b); provided that the Borrower’s obligations under Section 6.03(a) shall not be relieved by this Section 8.05(c).

  • Holder’s Right to Transfer If all of the Shares proposed in the Notice to be transferred to a given Proposed Transferee are not purchased by the Company and/or its assignee(s) as provided in this Section, then the Holder may sell or otherwise transfer such Shares to that Proposed Transferee at the Offered Price or at a higher price, provided that such sale or other transfer is consummated within 120 days after the date of the Notice, that any such sale or other transfer is effected in accordance with any applicable securities laws and that the Proposed Transferee agrees in writing that the provisions of this Section shall continue to apply to the Shares in the hands of such Proposed Transferee. If the Shares described in the Notice are not transferred to the Proposed Transferee within such period, a new Notice shall be given to the Company, and the Company and/or its assignees shall again be offered the Right of First Refusal before any Shares held by the Holder may be sold or otherwise transferred.

  • Lender’s Right to Cure If any Ground Lease Default shall occur and be continuing, or if any Ground Lessor asserts that a Ground Lease Default has occurred (whether or not the Borrowers question or deny such assertion), then, subject to the terms and conditions of the applicable Ground Lease, Lender, upon five (5) Business Days' prior written notice to the Borrowers, unless Lender reasonably determines that a shorter period (or no period) of notice is necessary to protect Lender's interest in the Ground Lease, may (but shall not be obligated to) take any action that Lender deems reasonably necessary, including, without limitation, (i) performance or attempted performance of the applicable Borrower's obligations under the applicable Ground Lease, (ii) curing or attempting to cure any actual or purported Ground Lease Default, (iii) mitigating or attempting to mitigate any damages or consequences of the same and (iv) entry upon the applicable Ground Leased Property for any or all of such purposes. Upon Lender's request, each Borrower shall submit satisfactory evidence of payment or performance of any of its obligations under each Ground Lease. Lender may pay and expend such sums of money as Lender in its sole discretion deems necessary or desirable for any such purpose, and the Borrowers shall pay to Lender within five (5) Business Days of the written demand of Lender all such sums so paid or expended by Lender, together with interest thereon from the date of expenditure at the Default Rate.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!