Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Authority to Enter Agreement Consultant has all requisite power and authority to conduct its business and to execute, deliver, and perform the Agreement. Each Party warrants that the individuals who have signed this Agreement have the legal power, right, and authority to make this Agreement and bind each respective Party.
Delegation of Authority to Act; Specified Actions 3.4.1 Subject to Section 3.1 and Section 3.2, Xxxxx Bank hereby grants to the Bank Assets Purchaser and Xxxxx Trust Company hereby grants to the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3), as Servicer hereunder, (a) the full right, power and authority to take any action (including any Specified Action) or to omit to take any action (including any Specified Action); provided that no such action or omission shall be taken unless it would be authorized if taken or omitted to be taken by the applicable Seller under the applicable Serviced Corporate Trust Contracts, and (b) all other rights, powers and entitlements of the Sellers under such Serviced Corporate Trust Contracts. In the event the parties identify any duties or obligations that are non-delegable under applicable Law or pursuant to the terms of the Serviced Corporate Trust Contracts, the parties agree to cooperate in good faith to determine how such duties or obligations are to be satisfied in a way to effect the original intent of the parties that the Purchasers have acquired the Business (and control thereof) and are entitled to receive the economic benefits and obligated to bear the economic burdens of the Serviced Appointments.
3.4.2 On the Closing Date, Xxxxx Bank shall execute and deliver to the Bank Assets Purchaser one or more legal powers of attorney in favor of the Bank Assets Purchaser and Xxxxx Trust Company shall execute and deliver to the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3) one or more legal powers of attorney in favor of the Delaware Trust Assets Purchaser (or the Bank Assets Purchaser, if required by Section 3.3), in each case, in form and content necessary and effective to authorize such persons to take any action (including any Specified Action) or to omit to take any action (including any Specified Action) and to execute documents or other papers in the applicable Seller’s place and stead, to the fullest extent necessary or appropriate for each applicable Purchaser to exercise the powers and perform the duties provided for hereunder, and following the Closing, the Sellers shall use reasonable best efforts to take all other such actions and execute such other documents as the Purchasers may from time to time reasonably request in order for them to exercise the powers and perform the duties provided for hereunder. For purposes of this Agreement, and without limiting the grant of authority in the preceding sentence, “Specified Action” means any action (including any determination to take no action) with respect to a Serviced Appointment, including any action (or determination to take no action) requiring or permitting the exercise of judgment in connection with decisions between or among alternative courses of action, which may include determinations with respect to the following:
Outage Authority and Coordination Developer and Connecting Transmission Owner may each, in accordance with NYISO procedures and Good Utility Practice and in coordination with the other Party, remove from service any of its respective Attachment Facilities or System Upgrade Facilities and System Deliverability Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency State, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to schedule such removal on a date and time mutually acceptable to both the Developer and the Connecting Transmission Owner. In all circumstances either Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Party of such removal.
GUIDELINES FOR THE EXERCISE OF DELEGATED AUTHORITY For purposes of this Section 3.2, the Board shall be deemed to have considered and determined to accept such Country Risk as is incurred by placing and maintaining the Foreign Assets in each country for which the Custodian is serving as Foreign Custody Manager of the Portfolios.
Instructions; Authority to Act The Servicer shall be deemed to have received proper instructions with respect to the Receivable Files upon its receipt of written instructions signed by a Trust Officer of the Indenture Trustee.
Authority to Carry on Business The Trustee represents to the Corporation that at the date of execution and delivery by it of this Indenture it is authorized to carry on the business of a trust company in each of the provinces and territories of Canada but if, notwithstanding the provisions of this Section 14.14, it ceases to be so authorized to carry on business, the validity and enforceability of this Indenture and the Debentures issued hereunder shall not be affected in any manner whatsoever by reason only of such event but the Trustee shall, within 60 days after ceasing to be authorized to carry on the business of a trust company in any of the provinces and territories of Canada, either become so authorized or resign in the manner and with the effect specified in Section 14.2.
Authority to Execute Agreement Each of the Parties represents and warrants that its undersigned representative has been expressly authorized to execute this Agreement for and on behalf of such Party.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
