Pre-award Conferences Sample Clauses

Pre-award Conferences. The CM, with the assistance of the A/E and the COUNTY, shall gather documentation for contract execution from apparent successful Bidders which may occur at pre-award conferences with such Bidders. Upon the failure of a Bidder to provide such documentation in a timely manner, the CM shall assist the COUNTY in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Pre-award Conferences. The Associate shall gather documentation for contract execution from apparently successful Bidders which may occur at pre-award conferences with such Bidders. Upon the failure of a Bidder to provide such documentation in a timely manner, the Associate shall assist the University in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1Sample 2
Pre-award Conferences. 6.6.1 The A/E shall conduct pre-award conferences with the apparent successful Bidder and shall assist the Contracting Authority to gather documentation for contract execution from such Bidder. 6.6.2 Upon the failure of the apparent successful Bidder to provide such documentation in a timely manner, the A/E shall assist the Contracting Authority in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1
Pre-award Conferences. The Architect shall attend pre-award conferences between the Construction Manager and the apparently successful Bidders. The Construction Manager shall notify the Architect in a timely manner as to the schedule for the conferences.
Sample 1
Pre-award Conferences. SitelogIQ, with the assistance of the Architect, shall gather documentation for contract execution from apparently successful bidders which may occur at Pre-Award Conferences with such bidders. Upon the failure of a bidder to provide such documentation in a timely manner, SitelogIQ shall assist the School District in considering whether an extension of time for submitting such documentation is appropriate.
Sample 1

Related to Pre-award Conferences

  • POST AWARD MEETING Within ten (10) days after receipt of notification of award of bid, Contractor shall meet with the County’s representative(s) to discuss job procedures and scheduling.

  • System for Award Management (XXX) and Data Universal Numbering System (DUNS) Requirements.

  • System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.

  • Award Criteria 40.1 The Procuring Entity shall award the Contract to the successful tenderer whose tender has been determined to be the Lowest Evaluated Tender in accordance with procedures in Section 3: Evaluation and Qualification Criteria.

  • Performance Award You are hereby awarded, on the Grant Date, a Performance Award with a target value of [AMOUNT].

  • Service Award Named Plaintiff may apply to the Court for a service award of up to ten thousand dollars ($10,000). Subject to the Court’s approval, the service award shall be paid from the Settlement Fund ten (10) days after the Effective Date.

  • Service Awards The County shall continue its present policy with respect to service awards including time off; provided, however, that the type of award given shall be at the sole discretion of the County. The following procedures shall apply with respect to service awards:

  • Stock Plan Administration Service Providers The Company transfers participant data to Xxxxxx Xxxxxxx, an independent service provider based in the United States, which assists the Company with the implementation, administration and management of the Plan. In the future, the Company may select a different service provider and share the Participant’s data with another company that serves in a similar manner. The Company’s service provider will open an account for the Participant to receive and trade Shares. The Participant will be asked to agree on separate terms and data processing practices with the service provider, which is a condition to the Participant’s ability to participate in the Plan.

  • Performance Share Awards On the Performance Share Vesting Date next following the Executive's date of death, the number of Performance Shares that shall become Vested Performance Shares shall be determined by multiplying (a) that number of shares of Company Common Stock subject to the Performance Share Agreement that would have become Vested Performance Shares had no such termination occurred; provided, however, in no case shall the number of Performance Shares that become Vested Performance Shares exceed 100% of the Target Number of Performance Shares set forth in the Performance Share Agreement, by (b) the ratio of the number of full months of the Executive's employment with the Company during the Performance Period (as defined in the Performance Share Agreement) to the number of full months contained in the Performance Period. Vested Common Shares shall be issued in settlement of such Vested Performance Shares on the Settlement Date next following the Executive’s date of death.

  • Performance Meetings During a meeting on performance, the parties will: (a) discuss the causes of a Performance Factor; (b) discuss the impact of a Performance Factor on the local health system and the risk resulting from non-performance; and (c) determine the steps to be taken to remedy or mitigate the impact of the Performance Factor (the “Performance Improvement Process”).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!