Pre-Term Possession. If Landlord is to construct or remodel the Premises, Landlord may notify Tenant when the Premises are ready for Tenant’s fixture installation or Tenant’s work. Tenant shall be granted access to the Premises as soon as reasonably possible (subject to not interfering with Landlord’s construction of the Tenant Improvements) and in any event at least fifteen (15) days prior to the Commencement Date for the purpose of installing Tenant’s furniture, fixtures and equipment. Tenant may then enter the Premises at its own risk to make such improvements, to install fixtures, supplies, inventory and other property. Tenant will not interfere with the progress of Landlord’s work by such entry. Should Landlord determine such entry interferes with its work, Landlord may demand that Tenant vacate the Premises until Landlord’s work is complete. Tenant shall promptly comply with this demand. During any pre-term possession all terms and conditions of the Lease shall apply, including Tenant indemnities under the Lease and Tenant’s payment of utilities, but excluding the payment of other Rent; provided, however, if Tenants opens for business in the Premises prior to the Commencement Date, Tenant shall pay Rent in the amount specified in Section 1.8(A).
Pre-Term Possession. Landlord will endeavor to permit Tenant to have early access to the Leased Premises approximately two (2) weeks prior to the Commencement Date for Tenant to make arrangements for the move into the Leased Premises, to perform certain alterations, and to allow Tenant to install its furniture, fixtures and equipment, provided, however, that any such early access shall not interfere or delay with the construction of the Tenant Improvements. Such early access will be provided in a written notice from Landlord to Tenant. Such early access by Tenant, or any agent, employee or contractor of Tenant, to the Leased Premises prior to the Commencement Date shall be subject to all the provisions of this Lease (other than the payment of Minimum Monthly Rent, Operating Cost and Taxes, and the start of the Minimum Rent Abatement Period), including, without limitation, Tenant’s compliance with the insurance and indemnity requirements of this Lease. Said early access shall not advance the termination date of this Lease. Tenant agrees that it shall not in any way interfere with the progress of the Tenant Improvements. Should such access prove an impediment to the progress of the Tenant Improvements, in Landlord’s reasonable judgment, Landlord may demand that Tenant forthwith vacate the Leased Premises until such time as Landlord’s work is complete, and Tenant shall immediately comply with this demand. Tenant shall comply with all terms and conditions of this Lease during the course of any pre-term possession, except as provided above.
Pre-Term Possession. In the event Landlord permits Tenant, or any agent, employee or contractor of Tenant, to enter, use or occupy the Leased Premises prior to the Commencement Date, such entry, use or occupancy shall be subject to all the provisions of this Lease other than the payment of Minimum Monthly Rent, including, without limitation, Tenant's compliance with the insurance and indemnity requirements of this Lease. Said early possession shall not advance the termination date of this Lease. In the event that Landlord so permits such early access to the leased Premises, Tenant agrees that it shall not in any way interfere with the progress of Landlord's work (if any) by such entry. Should such entry prove an impediment to the progress of Landlord's work, in Landlord's judgment, Landlord may demand that Tenant forthwith vacate the Leased Premises until such time as Landlord's work is complete, and Tenant shall immediately comply with this demand. Tenant shall comply with all terms and conditions of this Lease during the course of any pre-term possession, except for the payment of Minimum Monthly Rent.
Pre-Term Possession. Landlord agrees that Tenant and the agents, employees or contractors of Tenant may enter, use and occupy the Premises commencing approximately fifteen (15) days prior to the Commencement Date. Such pre-term possession for Tenant’s entry, use or occupancy shall be subject to all the provisions of this Lease other than the payment of Minimum Monthly Rent, including, without limitation, Tenant’s compliance with the insurance and indemnity requirements of this Lease. Said early possession shall not advance the termination date of this Lease. Tenant agrees that such early occupancy shall not materially interfere with the progress of Landlord’s work (if any) by such entry. Should such entry prove an impediment to the progress of Landlord’s work, in Landlord’s reasonable judgment, Landlord may demand that Tenant forthwith vacate the Premises until such time as Landlord’s work is complete, and Tenant shall immediately comply with this demand; provided, however, that Tenant shall in all events be provided with at least fifteen (15) days access to the Premises prior to the Commencement Date to prepare the Premises for Tenant’s occupancy.
Pre-Term Possession. If the Leased Premises are to be constructed or remodeled by Landlord, Landlord may notify Tenant when the Leased Premises are ready for Tenant’s fixturing or Tenant’s work, which may be prior to Substantial Completion of the Leased Premises by Landlord. Tenant may thereupon enter the Leased Premises for such purposes at its own risk, to make such improvements as Tenant shall have the right to make, to install fixtures, supplies, inventory and other property. Such entry by Tenant prior to the Substantial Completion of the Leased Premises by Landlord shall be referred to herein as “ Pre-Term Possession .” Tenant agrees that it shall not in any way interfere with the progress of Landlord’s work by such entry. Should such entry prove an impediment to the progress of Landlord’s work, in Landlord’s reasonable judgment, Landlord may demand that Tenant forthwith vacate the Leased Premises until such time as Landlord’s work is complete, and Tenant shall immediately comply with this demand. During the course of any Pre-Term Possession, all terms and conditions of this Lease, except for Tenant’s obligation to pay Minimum Monthly Rent, Operating Costs, Insurance Costs and Taxes, shall apply, particularly with reference to indemnity by Tenant of Landlord under Sections 10.4 and 14.4. Notwithstanding the foregoing, (a) in no event shall Tenant be required to indemnify Landlord for Losses (as defined in Section 10.4) caused by Landlord, its agents, contractors or sub-contractors during such Pre-Term Possession, and (b) during such Pre-Term Possession, Tenant’s insurance shall not be primary with respect to claims arising out of the acts or omissions of Landlord or Landlord’s agents, contractors or sub-contractors.
Pre-Term Possession. Following delivery of the Premises by Landlord, Tenant may enter the Premises at its own risk to construct the Tenant Improvements pursuant to Exhibit C hereto. During any period prior to the Commencement Date that Tenant is in possession of the Premises, all terms and conditions of the Lease shall apply, including Tenant indemnities under the Lease and Tenant's payment of utilities, but excluding the payment of other Rent. /s/ --------------------- ------------------- Landlord's Initials Tenant's Initials
Pre-Term Possession. Landlord shall deliver possession of the Premises to Tenant as soon as reasonably possible following the full execution hereof, and Tenant shall have the right during the period between the date Landlord delivers possession of the Premises to Tenant and the Commencement Date of the Lease to perform such improvements, alterations and additions to the Premises as Tenant shall desire, pursuant to Exhibit C hereto. During any such period of pre-term possession by Tenant, all terms and conditions of the Lease shall apply, including Tenant indemnities under the Lease and Tenant's payment of utilities, but excluding the payment of other Rent.
Pre-Term Possession. Tenant may have access to and use of the Premises from and after the Delivery Date to make such improvements, to install fixtures, supplies, inventory and other property. Tenant will not interfere with the progress of Landlord’s work by such entry. During any pre-term possession all terms and conditions of the Lease shall apply, including Tenant indemnities under the Lease and Tenant’s payment of utilities after the Delivery Date, but excluding the payment of other Rent. Landlord’s Initials Tenant’s Initials
Pre-Term Possession. (a) Conditions of Entry In the event the Leased Premises are to be constructed or remodeled by Lessor, Lessor may notify Lessee when the Leased Premises are ready for Lessee's fixturing or Lessee's Work, which may be prior to substantial completion of the Leased Premises by Lessor. Lessee may thereupon enter the Leased Premises for such purposes at its own risk, to make such improvements as Lessee shall have the right to make, to install fixtures, supplies, inventory and other property. Lessee agrees that it shall not in any way interfere with the progress of Lessor's Work by such entry. Should such entry prove an impediment to the progress of Lessor's Work, in Lessor's judgment, Lessor may demand that Lessee forthwith vacate the Leased Premises until such time as Lessor's work is complete, and Lessee shall immediately comply with this demand. In the event Lessor requires that Lessee vacate, the ninety (90) day time period specified in Section 2.1, "Commencement Date", (iii), shall be extended for the number of days Tenant has been required to vacate the Leased Premises.
Pre-Term Possession. Tenant is currently occupying the Premises pursuant to that certain Early Entry License entered into between Landlord and Tenant. Upon mutual execution of this Lease, Tenant may continue to occupy the Premises for its own risk, to make such improvements as Tenant shall have the right to make, to install fixtures, supplies, inventory and other property. Such occupancy by Tenant prior to the Substantial Completion of the Landlord Work shall be referred to herein as "Pre-
