Preliminary Plans Tenant shall prepare and submit to Landlord for approval schematics of the Tenant Improvements prepared in conformity with the applicable provisions of this Exhibit F (the “Preliminary Plans”). The Preliminary Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Preliminary Plans whether Landlord approves or objects to the Preliminary Plans and of Landlord’s specific objections to the Preliminary Plans (if any). Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Preliminary Plans, then Tenant shall revise the Preliminary Plans to remedy Landlord’s objections. Tenant shall then resubmit the revised Preliminary Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to any revised Preliminary Plans and Tenant’s correction of the same shall continue as provided above for the original Preliminary Plans until Landlord has approved the Preliminary Plans in writing. The Preliminary Plans that are approved by Landlord without objection shall be referred to as the “Approved Preliminary Plans.”
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Project Review A. Programmatic Allowances
1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification.
2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination.
3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review.
4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments.
B. Expedited Review for Emergency Undertakings
Preliminary Approval A. As soon as practicable after this Agreement is fully executed, for settlement purposes only, the Plaintiffs and Co-Lead Counsel shall request the Court to make preliminary findings, enter the Preliminary Approval Order granting conditional certification of the Class, subject to final findings and ratification in the Final Order and Judgment, and appoint the Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class. Neither Defendant nor Defendant’s Counsel will object to such requests for the purposes of effectuating the Settlement. Such agreement not to object to class certification shall extend only as necessary to effectuate the Settlement. As set forth in the draft Preliminary Approval Order, the Plaintiffs shall request the Court to enter an order:
1. preliminarily approving and finding this Agreement and the Settlement as being fair, reasonable, and adequate;
2. conditionally certifying the Litigation as a settlement class action under Rule 23(b)(3) and (e) of the Federal Rules of Civil Procedure;
3. appointing Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class;
4. preliminarily approving the form, manner, and content of the Class Notice, as provided herein, and finding that notice is fair, reasonable, and the best notice practicable under the circumstances in connection with notifying the Class Members of their rights and responsibilities under the Settlement and satisfying due process and Rule 23 of the Federal Rules of Civil Procedure;
5. appointing the Settlement Administrator to send Class Notice and administer the Settlement;
6. providing that Class Members will have until a date certain to object to or file a request for exclusion from the Settlement, as provided herein;
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Marketing Plans Contractor and the Exchange recognize that Enrollees and other health care consumers benefit from efforts relating to outreach activities designed to increase heath awareness and encourage enrollment. The parties shall share marketing plans on an annual basis and with respect to periodic updates of material changes. The marketing plans of each of the Exchange and Contractor shall include proposed marketing approaches and channels and shall provide samples of any planned marketing materials and related collateral as well as planned, and when completed, expenses for the marketing budget. The Contractor shall include this information for both the Exchange and the outside individual market. The Exchange shall treat all marketing information provided under this Section as confidential information and the obligation of the Exchange to maintain confidentiality of this information shall survive termination or expiration of this Agreement.
Design Review
(a) Where so specified in Schedule A (Scope of Goods and Services) or as otherwise instructed by the City, the Supplier shall submit design-related Documentation for review by the City, and shall not proceed with work on the basis of such design Documentation until the City’s approval of such Documentation has been received in writing.
(b) None of:
(i) the submission of Documentation to the City by the Supplier;
(ii) its examination by or on behalf of the City; or
(iii) the making of any comment thereon (including any approval thereof) shall in any way relieve the Supplier of any of its obligations under this Agreement or of its duty to take reasonable steps to ensure the accuracy and correctness of such Documentation, and its suitability to the matter to which it relates.
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
