Preparation and Submission The Recipient will:
Preparation of Agreement This Agreement shall not be construed more strongly against any party regardless of who is responsible for its preparation. The parties acknowledge each contributed and is equally responsible for its preparation.
Initiation and Processing 1. Level One
Preparation Awarded vendor shall not begin a project for which TIPS Member has not prepared the site, unless awarded vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in a purchase order. Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre-installation requirements. Registered sex offender restrictions: For work to be performed at schools, awarded vendor agrees that no employee of a sub-contractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present. Awarded vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the purchase order at the TIPS Member’s discretion. Awarded vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety measures: Awarded vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Awarded vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage.
Preparations No more than three (3) preparations per professor per term shall be the goal of the District and the Association. If more than three (3) preparations are necessary to meet particular needs of students or to meet the unique needs of a department, such additional preparations will only be assigned by the appropriate administrator following discussion with all affected members of the department. When such additional preparations are necessary, they shall be distributed equitably among department members.
Transportation and Delivery Prices shall include all charges for packing, handling, freight, distribution, and inside delivery. Transportation of goods shall be FOB Destination to any point within thirty (30) days after the Customer places an Order. A Contractor, within five (5) days after receiving a purchase order, shall notify the Customer of any potential delivery delays. Evidence of inability or intentional delays shall be cause for Contract cancellation and Contractor suspension.
Planning and Preparation 1. Uses established local and the Core Curriculum Standards and Cumulative Progress Indicators as well as established local and state curriculum objectives in planning lessons.
INSPECTION AND REJECTION 8.1 Purchaser shall have the right to inspect and test Products at any time prior to shipment, and within a reasonable time after delivery to the Purchaser’s Destination. Products not inspected within a reasonable time after delivery shall be deemed accepted by Purchaser. The payment for Products shall in no way impair the right of Purchaser to reject nonconforming Products, or to avail itself of any other remedies to which it may be entitled.
PRINTING OF AGREEMENTS 35.1 The Company will undertake the responsibility for the printing of the collective agreements as may be required from time to time and will absorb the cost of such printing. This will include the cost of printing updated pages.
Professional Preparation and Scholarship The certificated classroom teacher exhibits, in his/her performance, evidence of having a theoretical background and knowledge of the principles and methods of teaching, and a commitment to education as a profession.