Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Project Reports The Recipient shall monitor and evaluate the progress of the Project and prepare Project Reports in accordance with the provisions of Section 4.08 of the General Conditions and on the basis of the indicators agreed with the Association. Each Project Report shall cover the period of one calendar semester, and shall be furnished to the Association not later than one month after the end of the period covered by such report.
Final Project Report Prepare a Final Project Report that addresses, to the extent feasible, comments made by the Grant Manager on the Draft Final Project Report. Submit one (1) reproducible master and an electronic copy of the final. Upload an electronic copy of the final report in pdf format to the FAAST system.
Contract Reporting The Contractor shall report information on orders received from Customers associated with this Contract. No price adjustments will be considered for any Contractor who has outstanding reports, or any other documentation required under this Contract. The Contractor shall submit reports in accordance with the following schedule: MFMP Transaction Fee Report Calendar month 15 calendar days after the end of each month Quarterly Sales Report State’s Fiscal Quarter 30 calendar days after close of the period Diversity Report(submitted to the Customer) State Fiscal Year 30 Business Days after close of the period Preferred Pricing Affidavit (in accordance with the Special Contract Conditions) Annual Contract Anniversary Date
Product Returns Client will have the responsibility for handling customer returns of the Products. Patheon will give Client any assistance that Client may reasonably require to handle the returns.
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
COST REPORT 27 A. CONTRACTOR shall submit separate individual and/or consolidated Cost Reports for Period 28 One, Period Two, and Period Three, or for a portion thereof, to COUNTY no later than sixty (60) 29 calendar days following the period for which they are prepared or termination of this Agreement. 30 CONTRACTOR shall prepare the individual and/or consolidated Cost Report in accordance with all 31 applicable federal, state and COUNTY requirements, GAAP and the Special Provisions Paragraph of 32 this Agreement. CONTRACTOR shall allocate direct and indirect costs to and between programs, cost 33 centers, services, and funding sources in accordance with such requirements and consistent with prudent 34 business practice, which costs and allocations shall be supported by source documentation maintained 35 by CONTRACTOR, and available at any time to ADMINISTRATOR upon reasonable notice. In the 36 event CONTRACTOR has multiple Agreements for mental health services that are administered by 37 HCA, consolidation of the individual Cost Reports into a single consolidated Cost Report may be 1 required, as stipulated by ADMINISTRATOR. CONTRACTOR shall submit a consolidated Cost 2 Report to COUNTY no later than five (5) business days following approval by ADMINSTRATOR of 3 all individual Cost Reports to be incorporated into a consolidated Cost Report.
4 1. If CONTRACTOR fails to submit an accurate and complete individual and/or consolidated 5 Cost Report within the time period specified above, ADMINISTRATOR shall have sole discretion to 6 impose one or both of the following:
7 a. CONTRACTOR may be assessed a late penalty of five hundred dollars ($500) for each 8 business day after the above specified due date that the accurate and complete individual and/or 9 consolidated Cost Report is not submitted. Imposition of the late penalty shall be at the sole discretion 10 of the ADMINISTRATOR. The late penalty shall be assessed separately on each outstanding individual 11 and/or consolidated Cost Report due COUNTY by CONTRACTOR.
12 b. ADMINISTRATOR may withhold or delay any or all payments due CONTRACTOR 13 pursuant to any or all agreements between COUNTY and CONTRACTOR until such time that the 14 accurate and complete individual and/or consolidated Cost Report is delivered to ADMINISTRATOR.
15 2. CONTRACTOR may request, in advance and in writing, an extension of the due date of the 16 individual and/or consolidated Cost Report setting forth good cause for justification of the request.
Adverse Event Reporting Both Parties acknowledge the obligation to comply with the Protocol and / or applicable regulations governing the collection and reporting of adverse events of which they may become aware during the course of the Clinical Trial. Both Parties agree to fulfil and ensure that their Agents fulfil regulatory requirements with respect to the reporting of adverse events.
GRIEVANCE REPORT FORM Grievance # School District Distribution of Form 1. Superintendent
