Control Documents Except as disclosed in Section 4.13 of the Disclosure Schedule, each of the representations and warranties as follows is true and accurate with respect to Domestic Companies:
(a) The Control Documents enable the Company to consolidate the Financial Statements with the Domestic Companies. Each party to the Control Documents has the legal right, power and authority (corporate and other) to enter into and perform its obligations under each Control Document to which it is a party and has taken all necessary corporate action to authorize the execution, delivery and performance of, and has authorized, executed and delivered, each Control Document to which it is a party.
(b) Each executed Control Document constitutes a valid and legally binding obligation of the parties named therein enforceable in accordance with its terms, except (i) as limited by applicable bankruptcy, insolvency, reorganization, moratorium and other laws of general application affecting enforcement of creditors’ rights generally, and (ii) as limited by Laws relating to the availability of specific performance, injunctive relief or other remedies in the nature of equitable remedies.
(c) Each Control Document is in proper legal form under applicable Law of the PRC for the enforcement thereof against each of the parties thereto in the PRC without further action by any of them except (i) as limited by applicable bankruptcy, insolvency, reorganization, moratorium, and other laws of general application affecting enforcement of creditors’ rights generally, and (ii) as limited by Laws relating to the availability of specific performance, injunctive relief, or other equitable remedies.
(d) The execution and delivery by each party named in each Control Document, and the performance by such party of its obligations thereunder and the consummation by it of the transactions contemplated therein shall not (i) result in any violation of, be in conflict with, or constitute a default under, with or without the passage of time or the giving of notice, any provision of its corporate documents as in effect at the date hereof, any applicable Law, or any contract to which any Group Company is a party or by which any Group Company is bound, (ii) accelerate, or constitute an event entitling any Person to accelerate, the maturity of any indebtedness or other liability of any Group Company or to increase the rate of interest presently in effect with respect to any indebtedness of any Group Company, or (iii) result in the creation of any Lien upon any of the properties or assets of any Group Company.
(e) All consents required in connection with the Control Documents have been made or unconditionally obtained in writing, and no such consent has been withdrawn or is subject to any condition precedent, which has not been fulfilled or performed.
(f) Each Control Document is in full force and effect and no party to any Control Document is in breach or default in the performance or observance of any of the terms or provisions of such Control Document. None of the parties to any Control Document has sent or received any communication regarding termination of or intention not to renew any Control Document, and no such termination or non-renewal has been threatened by any of the parties thereto.
(g) The share pledge agreements as part of the Control Documents of Domestic Companies have been duly registered with competent PRC Governmental Authority.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Project Documentation All documentation provided to the City other than Project drawings shall be furnished on a Microsoft compatible compact disc.
Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project:
A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions
B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 (English units)
Project Contracts Prior to the delivery of this Lease, the Company may have entered into a contract or contracts with respect to the acquisition and/or construction of the Improvements. Those contracts, and any such contracts entered into by the Company after delivery of this Lease are hereinafter referred to as the “Project Contracts.” Prior to the delivery hereof, certain work has been or may have been performed on the Improvements pursuant to said Project Contracts or otherwise. Subject to the Lender’s rights in the Project Contracts, the Company hereby conveys, transfers and assigns to the Issuer all of the Company’s rights in, but not its obligations under the Project Contracts and the Issuer hereby designates the Company as Issuer’s agent for the purpose of executing and performing the Project Contracts. After the execution hereof, the Company shall cause the Project Contracts to be fully performed by the contractor(s), subcontractor(s) and supplier(s) thereunder in accordance with the terms thereof, and the Company covenants to cause the Improvements to be acquired, constructed and/or completed in accordance with the Project Contracts. Any and all amounts received by the Issuer, the Trustee or the Company from any of the contractors or other suppliers by way of breach of contract, refunds or adjustments shall become a part of and be deposited in the Project Fund.
Design Development Documents See Section 2, Part 1, Article 2.1.5.
Design Documents Prepare and submit the following documents to the DAS - Records Management Office with a copy of the transmittal letter submitted to the respective Project Manager:
1. City/State Approved Drawings (1) Original set
2. Bid Set Drawings (1) Set BOND PAPER (marked as “ORIGINAL”)
(1) Set electronic file (DWG & PDF)
3. Project Manual
(1) Set hard copy & Detail Manual (1) Set electronic file
Project Agreement 1.1 If applicable, the Department will recommend approval of the project by the Federal Highway Administration.
1.2 The Sponsor agrees to comply with Title VI of the Civil Rights Act of 1964, 78 Stat. § 252, 42 U.S.C. § 2000d et seq., and all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, Part 21 - “Nondiscrimination in federally assisted programs of the Department of Transportation - effectuation of Title VI of the Civil Rights Act 1964".
1.3 The DEPARTMENT and SPONSOR mutually recognize that each party is a governmental entity subject to the provisions of the Governmental Tort Claims Act (51 O.S. § 151 et seq.). The DEPARTMENT and SPONSOR hereby mutually agree that each is and may be held severally liable for any and all claims, demands, and suits in law or equity, of any nature whatsoever, paying for damages or otherwise, arising from any negligent act or omission of any of their respective employees, agents or contractors which may occur during the prosecution or performance of this Agreement to the extent provided in the Governmental Tort Claims Act. Each party agrees to severally bear all costs of investigation and defense of claims arising under the Governmental Tort Claims Act and any judgments which may be rendered in such cause to the limits provided by law. Nothing in this section shall be interpreted or construed to waive any legal defense which may be available to a party or any exemption, limitation or exception which may be provided by the Governmental Tort Claims Act.
1.4 The Sponsor understands that should it fail to fulfill its responsibilities under this Agreement, such a failure will disqualify the Sponsor from future Federal-aid funding participation on any proposed project. Federal-aid funds are to be withheld until such a time as an engineering staff, satisfactory to the Department has been properly established and functioning, the deficiencies in regulations have been corrected or the improvements to be constructed under this Agreement are brought to a satisfactory condition of maintenance.
Construction Documents Phase Bidding or Negotiation Phase:
Project Agreements Provided that where the company commences work on a project where a site agreement exists to which the company is contractually obligated or where a site agreement exists between the union and the client or their agent that provides for higher rates of pay and conditions, the conditions contained in any such site agreement will take precedence over this Agreement for the duration of the project.
