Project Time Frame Clause Samples
The Project Time Frame clause defines the specific period during which the project is expected to commence and be completed. It typically outlines the start and end dates, and may include provisions for extensions or adjustments due to unforeseen circumstances such as delays or force majeure events. By clearly establishing the timeline, this clause ensures that all parties have a mutual understanding of deadlines, helping to manage expectations and reduce the risk of disputes related to project scheduling.
POPULAR SAMPLE Copied 7 times
Project Time Frame. Poinciana and ▇▇▇▇▇▇’▇ Walk acknowledge that the Restated Poinciana Lease requires ▇▇▇▇▇▇’▇ Walk to commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Restated Poinciana Lease provides that the Completion Date shall be automatically extended one day for each day of Unavoidable Delay. The Completion Date may also be extended as provided in the Restated Poinciana Lease. The term “Unavoidable Delay” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area-wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds.
Project Time Frame. Borrower shall complete the project by December 31, 2011 and receive a certificate of occupancy.
Project Time Frame. Borrower shall use commercially reasonable efforts to achieve the timeframe outlined in the associated Grant Application.
Project Time Frame. Developer shall commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Completion Date shall be automatically extended one day for each day of Unavoidable Delays. The term “Unavoidable Delays” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area- wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds. In the event of the occurrence of any such Unavoidable Delay, the time or times for the performance of the covenants, provisions and agreements of this Lease, shall be extended for the period of delay actually caused by the Unavoidable Delay; provided, however, that the party seeking the benefit of the provisions of this Section 3.4.2 shall, within ten (10) days after such party shall have become aware of such Unavoidable Delay, give written notice to the other party, stating the event purportedly constituting the Unavoidable Delay and as soon as reasonably possible thereafter provide written notice to the other party of the additional period of time required for any performance as a result of the Unavoidable Delay. The failure to provide such notice shall constitute the waiver of right of that party to claim that an Unavoidable Delay has occurred. Any dispute between the Developer and the CRA as to whether an Unavoidable Delay has occurred and/or the duration of the delay caused by the Unavoidable Delay shall be decided by arbitration pursuant to Article XXIII of this Lease at the request of either party. Developer may extend Completion Date, as same may be extended by Unavoidable Delays for an additional twenty-four
Project Time Frame. Proposed Project Time Frame
Project Time Frame. Agreement to the terms, and the receipt of the Initial Payments are required prior to project start. Project Start date is upon signing this agreement. Project Completion Time Frame is 8-12 weeks from Project Start Date. Project Time Frame is an estimate based on next-day feedback, where feedback is needed. Delays in feedback beyond next-day will push the Time Frame back the same number of days as has been delayed.
Project Time Frame. The time frame outlined in the Grant Application pertaining to the Project shall be met by the Borrower.
Project Time Frame. This is a 36‐month contract. The period of performance is July 12, 2010 through June 30, 2013.
Project Time Frame. The parties anticipate that the following steps will be taken to complete the Project and that each step will be taken by the dates specified: