Responsibility of Contractor a. Contractor shall be held strictly responsible for the proper performance of all work covered by the Contract Documents, including all work performed by Subcontractors. All work performed under this Contract shall comply in every respect to the rules and regulations of all agencies having jurisdiction over the Project or any part thereof.
b. Contractor shall submit Verified Reports as defined in §§4-336 and 4-343 (c), Group 1, Chapter 4, Part I, Title 24, California Code of Regulations (“CCR”). The duties of the Contractor are as defined in §4-343, Group 1, Chapter 4, Part I, Title 24, of the CCR. Contractor shall keep and make available a copy of Title 24 of the CCR at the job site at all times.
c. Where, because of short supply, any item of fabricated materials and/or equipment, indicated on drawings or specified is unobtainable and it becomes necessary, with the consent of the Project Manager, to substitute equivalent items differing in details or design, the Contractor shall promptly submit complete drawings and details indicating the necessary modifications of the work. This provision shall be governed by the terms of the General Conditions regarding Submittals: Shop Drawings, Cuts and Samples.
d. With respect to work performed at and near a school site, Contractor shall at all times take all appropriate measures to ensure the security and safety of students and staff, including, but not limited to, ensuring that all of Contractor’s employees, Subcontractors, and suppliers entering school property strictly adhere to all applicable District policies and procedures, e.g., sign-in requirements, visitor badges, and access limitations.
Responsibility of PFPC (a) PFPC shall be under no duty to take any action on behalf of the Fund except as specifically set forth herein or as may be specifically agreed to by PFPC in writing. PFPC shall be obligated to exercise care and diligence in the performance of its duties hereunder, to act in good faith and to use its best efforts in performing services provided for under this Agreement. PFPC shall be liable for any damages arising out of PFPC's failure to perform its duties under this Agreement to the extent such damages arise out of PFPC's willful misfeasance, bad faith, negligence or reckless disregard of such duties.
(b) Without limiting the generality of the foregoing or of any other provision of this Agreement, PFPC shall not be under any duty or obligation to inquire into and shall not be liable for (A) the validity or invalidity or authority or lack thereof of any Oral Instruction or Written Instruction, notice or other instrument which conforms to the applicable requirements of this Agreement, and which PFPC reasonably believes to be genuine; or (B) subject to Section 10, delays or errors or loss of data occurring by reason of circumstances beyond PFPC's control, including acts of civil or military authority, national emergencies, labor difficulties, fire, flood, catastrophe, acts of God, insurrection, war, riots or failure of the mails, transportation, communication or power supply.
(c) Notwithstanding anything in this Agreement to the contrary, neither PFPC nor its affiliates shall be liable to the Fund for any consequential, special or indirect losses or damages which the Fund may incur or suffer by or as a consequence of PFPC's or its affiliates' performance of the services provided hereunder, whether or not the likelihood of such losses or damages was known by PFPC or its affiliates.
(d) Notwithstanding anything in this Agreement to the contrary, the Fund shall not be liable to PFPC nor its affiliates for any consequential, special or indirect losses or damages which PFPC or its affiliates may incur or suffer by or as a consequence of PFPC's performance of the services provided hereunder, whether or not the likelihood of such losses or damages was known by the Fund.
Responsibility of student to attend school on every school day for the educational program in which they are enrolled, on time, ready to learn and take part in school activities • act at all times with respect and show tolerance towards other students and staff • work hard and comply with requests or directions from the teacher and principal • abide by school rules as outlined in the school’s Responsible Behaviour Plan for Students, including not bringing items to school which could be considered as weapons (e.g. dangerous items such as knives) • meet homework requirements and wear school’s uniform • respect the school property.
RESPONSIBILITY OF CONSULTANT Consultant shall take all responsibility for the work, shall bear all losses and damages directly or indirectly resulting to Consultant, to any subcontractor, to the City, to City officers and employees, or to parties designated by the City, on account of the performance or character of the work, unforeseen difficulties, accidents, occurrences or other causes to the extent predicated on active or passive negligence of the Consultant or of any subcontractor.
Responsibility for Property Except as expressly set forth in Section 3.25, Contractor shall limit its operations to the Stage 2 Site. Contractor shall plan and conduct its operations so that neither Contractor nor any of its Subcontractors or Sub-subcontractors shall (i) enter upon lands (other than the Stage 2 Site and Off-Site Rights of Way and Easements) or waterbodies in their natural state unless authorized by the appropriate owner or entity; (ii) close or obstruct any utility installation, highway, waterway, harbor, road or other property unless Permits are obtained and authorized by the appropriate entity or authority; or (iii) disrupt or otherwise interfere with the operation of any portion of any pipeline, telephone, conduit or electric transmission line, ditch, navigational aid, dock or structure unless otherwise specifically authorized by the appropriate entity or authority. The foregoing includes damage arising from performance of the Work through operation of Construction Equipment or stockpiling of materials. If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.
Responsibility of Parties 51.3.1 The Parties agree to abide by the following if a forecast cannot be agreed to: Local Interconnection Trunk Groups will be provisioned to the higher forecast. A blocking standard of one percent (1%) during the average busy hour shall be maintained. Should the Parties not agree upon the forecast, and the Parties engineer facilities at the higher forecast, the Parties agree to abide by the following:
a. In the event that CLEC over-forecasts its trunking requirements by twenty percent (20%) or more, and CenturyLink acts upon this forecast to its detriment, CenturyLink may recoup any actual and reasonable expense it incurs.
b. The calculation of the twenty percent (20%) over-forecast will be based on the number of DS1 equivalents for the total traffic volume exchanged between the Parties.
51.3.2 In addition to the joint trunk group forecasting established in Section 51.1, discussions to provide relief to existing facilities can be initiated by either Party. Actual system augmentations will be initiated upon mutual agreement.
51.3.3 Both Parties will perform a joint validation to ensure current Interconnection Facilities and associated trunks have not been over-provisioned. If any facilities and/or associated trunks are over-provisioned, they will be turned down where appropriate. Trunk design blocking criteria described in Section 64.3.4 will be used in determining trunk group sizing requirements and forecasts.
51.3.4 If, based on the forecasted equivalent DS-1 growth, the existing facilities are not projected to exhaust within one year, the Parties will suspend further relief planning on this Interconnection until a date one (1) year prior to the projected exhaust date. If growth patterns change during the suspension period, either Party may re-initiate the joint planning process.
51.3.5 Both Parties will negotiate a project service date and corresponding work schedule to construct relief facilities prior to facilities exhaust.
Responsibility of Custodian So long as and to the extent that it is in the exercise of reasonable care, the Custodian shall not be responsible for the title, validity or genuineness of any property or evidence of title thereto received by it or delivered by it pursuant to this Contract and shall be held harmless in acting upon any notice, request, consent, certificate or other instrument reasonably believed by it to be genuine and to be signed by the proper party or parties, including any futures commission merchant acting pursuant to the terms of a three-party futures or options agreement. The Custodian shall be held to the exercise of reasonable care in carrying out the provisions of this Contract, but shall be kept indemnified by and shall be without liability to the Fund for any action taken or omitted by it in good faith without negligence. It shall be entitled to rely on and may act upon written advice of counsel (who may be counsel for the Fund) on all matters, and shall be without liability for any action reasonably taken or omitted pursuant to such advice. Except as may arise from the Custodian’s own negligence or willful misconduct or the negligence or willful misconduct of a sub-custodian or agent, the Custodian shall be without liability to the Fund for any loss, liability, claim or expense resulting from or caused by; (i) events or circumstances beyond the reasonable control of the Custodian or any sub-custodian or U.S. or Foreign Securities System or any agent or nominee of any of the foregoing, including, without limitation, nationalization or expropriation, imposition of currency controls or restrictions, the interruption, suspension or restriction of trading on or the closure of any securities market, power or other mechanical or technological failures or interruptions, computer viruses or communications disruptions, acts of war or terrorism, riots, revolutions, work stoppages, natural disasters or other similar events or acts; (ii) errors by the Fund or the Investment Adviser in their instructions to the Custodian provided such instructions have been in accordance with this Contract; (iii) the insolvency of or acts or omissions by a U.S. or Foreign Securities System; (iv) any delay or failure of any broker, agent or intermediary, central bank or other commercially prevalent payment or clearing system to deliver to the Custodian’s sub-custodian or agent securities purchased or in the remittance or payment made in connection with securities sold; (v) any delay or failure of any company, corporation, or other body in charge of registering or transferring securities in the name of the Custodian, the Fund, the Custodian’s sub-custodians, nominees or agents or any consequential losses arising out of such delay or failure to transfer such securities including non-receipt of bonus, dividends and rights and other accretions or benefits; (vi) delays or inability to perform its duties due to any disorder in market infrastructure with respect to any particular security or U.S. or Foreign Securities System; and (vii) any provision of any present or future law or regulation or order of the United States, or any state thereof, or any other country, or political subdivision thereof or of any court of competent jurisdiction. The Custodian shall be liable for the acts or omissions of a foreign banking institution to the same extent as set forth with respect to sub-custodians generally in this Contract. If the Fund requires the Custodian to take any action with respect to securities, which action involves the payment of money or which action may, in the opinion of the Custodian, result in the Custodian or its nominee assigned to the Fund being liable for the payment of money or incurring liability of some other form, the Fund, as a prerequisite to requiring the Custodian to take such action, shall provide indemnity to the Custodian in an amount and form satisfactory to it. If the Fund requires the Custodian, its affiliates, subsidiaries or agents, to advance cash or securities for any purpose (including but not limited to securities settlements, foreign exchange contracts and assumed settlement) or in the event that the Custodian or its nominee shall incur or be assessed any taxes, charges, expenses, assessments, claims or liabilities in connection with the performance of this Contract, except such as may arise from its or its nominee’s own negligent action, negligent failure to act or willful misconduct, any property at any time held for the account of the applicable Fund shall be security therefor and should the Fund fail to repay the Custodian promptly, the Custodian shall be entitled to utilize available cash and to dispose of such Fund’s assets to the extent necessary to obtain reimbursement. In no event shall either party be liable to the other for indirect, special or consequential damages.
Responsibility of school staff to design and implement engaging and flexible learning experiences for individuals and groups of students
Responsibility of Each Party 5.22.1 Each Party is an independent contractor, and has and hereby retains the right to exercise full control of and supervision over its own performance of its obligations under this Agreement and retains full control over the employment, direction, compensation and discharge of all employees assisting in the performance of such obligations. Each Party will be solely responsible for all matters relating to payment of such employees, including compliance with social security taxes, withholding taxes and all other regulations governing such matters. Each Party will be solely responsible for proper handling, storage, transport and disposal at its own expense of all (i) substances or materials that it or its contractors or agents bring to, create or assume control over at Work Locations, and (ii) Waste resulting there from or otherwise generated in connection with its or its contractors' or agents' activities at the Work Locations. Subject to the limitations on liability and except as otherwise provided in this Agreement, each Party shall be responsible for (i) its own acts and performance of all obligations imposed by Applicable Law in connection with its activities, legal status and property, real or personal, and
RESPONSIBILITY OF PFPC TRUST (a) PFPC Trust shall be under no duty to take any action on behalf of the Fund or any Portfolio except as specifically set forth herein or as may be specifically agreed to by PFPC Trust in writing. PFPC Trust shall be obligated to exercise care and diligence in the performance of its duties hereunder, to act in good faith and to use its best efforts, within reasonable limits, in performing services provided for under this Agreement. PFPC Trust agrees to indemnify and hold harmless the Fund from Losses arising out of PFPC Trust's failure to perform its duties under this Agreement to the extent such damages arise out of PFPC Trust's willful misfeasance, bad faith, negligence or reckless disregard of its duties under this Agreement.
(b) Without limiting the generality of the foregoing or of any other provision of this Agreement, (i) PFPC Trust shall not be under any duty or obligation to inquire into and shall not be liable for (A) the validity or invalidity or authority or lack thereof of any Oral Instruction or Written Instruction, notice or other instrument which conforms to the applicable requirements of this Agreement, and which PFPC Trust reasonably believes to be genuine; or (B) subject to Section 10 of this Agreement, delays or errors or loss of data occurring by reason of circumstances beyond PFPC Trust's control, including acts of civil or military authority, national emergencies, fire, flood, catastrophe, acts of God, insurrection, war, riots or failure of the mails, transportation, communication or power supply.
(c) Notwithstanding anything in this Agreement to the contrary, neither PFPC Trust nor its affiliates shall be liable to the Fund or to any Portfolio for any consequential, special or indirect losses or damages which the Fund may incur or suffer by or as a consequence of PFPC Trust's or its affiliates' performance of the services provided hereunder, whether or not the likelihood of such losses or damages was known by PFPC Trust or its affiliates.
