Schedule, Completion Date, and Term of Agreement. Consultant warrants and represents that it will perform its services in a prompt and timely manner, which shall not impose delays on the progress of the Work. This Agreement shall commence as of the date first written above, and the Work shall be completed by . If the Term of this Agreement is longer than one year, the Parties agree that this Agreement, as required by O.C.G.A. § 36-60-13, shall terminate absolutely and without further obligation on the part of the County on December 31 each calendar year of the Term [ unless this box is checked, in which case the Agreement shall terminate absolutely and without further obligation on the part of the County at the end of the County’s fiscal year each year of the Term], and further, that this Agreement shall automatically renew on January 1 of each subsequent calendar year [ unless this box is checked, in which case the Agreement shall automatically renew on the first day of each subsequent County fiscal year of the Term] absent the County’s provision of written notice of non-renewal to Consultant at least five (5) days prior to the end of the then current calendar or fiscal year, as applicable. Title to any supplies, materials, equipment, or other personal property shall remain in Consultant until fully paid for by the County.
Schedule, Completion Date, and Term of Agreement. Contractor warrants and represents that it will perform its services in a prompt and timely manner, which shall not impose delays on the progress of the Work. This Agreement shall commence upon execution of the Agreement by both parties and shall absolutely terminate on June 30, of each year without further obligation on the part of County at the close of the calendar year in which it is executed and at the close of each succeeding year for which it may be renewed. This contract may be renewed by the parties for up to four (4) additional one year periods. In the event of termination of this Agreement by Contractor or by the Court, the Contractor shall be entitled to receive payment only for verified work actually performed prior to termination. The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this Agreement upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by Contractor for the purpose of securing business and that the Contractor has not received any non-County fee related to this Agreement without the prior written consent of the County. For breach or violation of this warranty, the County shall have the right to annul this Agreement without liability or at its discretion to deduct from the Agreement Price of consideration the full amount of such commission, percentage, brokerage or contingent fee.
Schedule, Completion Date, and Term of Agreement. Contractor warrants and represents that it will perform its services in a prompt and timely manner, which shall not impose delays on the progress of the Work. This Agreement shall commence as of the date first written above, and the Work shall be completed on or before / /2024. The Agreement may be extended for additional periods predicated on satisfactory performance and appropriation for lawn maintenance services by the DDA.
Schedule, Completion Date, and Term of Agreement. Consultant understands that time is of the essence of this Agreement and warrants and represents that it will perform the Work in a prompt and timely manner, which shall not impose delays on the progress of the Work. The term of this Agreement (“Term”) shall be deemed to have commenced on October 1, 2021, and the Work shall be completed, and the Agreement shall terminate, on September 30, 2022 (provided that certain obligations will survive termination/expiration of this Agreement). If the Term of this Agreement is longer than one year, the Parties agree that this Agreement, as required by O.C.G.A. § 36-60-13, shall terminate absolutely and without further obligation on the part of City on September 30 each fiscal year of the Term, and further, that this Agreement shall automatically renew on October 1 of each subsequent fiscal year during the Term, absent City’s provision of written notice of non-renewal to Consultant at least five (5) days prior to the end of the then current fiscal year. Title to any supplies, materials, equipment, or other personal property shall remain in Consultant until fully paid for by City.
