Schedule of Design Services Sample Clauses

Schedule of Design Services. As a supplement to and consistent with the project schedule attached hereto and referenced in Paragraph 1.2, and to the extent not already a part of said project schedule, Design/Builder shall submit for Owner’s approval a design schedule for the performance of Design/Builder’s Design Services which shall include allowance for reasonable time required for Owner’s review of submissions and for approvals of authorities having jurisdiction over the Project, and which shall describe in detail the break-down of the portions of the Detailed Design specified by Design/Builder in completing the entire Detailed Design, and the dates by which those specified portions of the Detailed Design will be completed. The design schedule, when approved by Owner, shall not, except for good cause, be exceeded by Design/Builder. Should Design/Builder, at any time during the course of performing the Agreement, have any reason to believe that it will be unable to meet any completion date in accordance with the design schedule, it shall promptly notify Owner’s Representative in writing. In such notice, Design/Builder shall state the reason for the delay, including the party responsible, if any, and the steps being taken to remedy or minimize the impact of the delay. Failure of Design/Builder to submit such notice shall constitute a waiver by Design/Builder of any claim for an adjustment to the design schedule or the Contract Time. Subject to the provisions of Paragraph 12.7 of this Agreement, Owner shall review and approve, where appropriate, the design schedule, or any portion thereof. The design schedule shall be incorporated into and be a part of the project schedule.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Schedule of Design Services. Design/Builder shall submit for Owner's approval the Design Schedule for the performance of Design/Builder's Design Services which shall include allowance for reasonable time required for Owner's review of submissions and for approvals of authorities having jurisdiction over the Project. The Design Schedule, when approved by Owner, shall not, except for good cause, be exceeded by Design/Builder. Should Design/Builder at any time during the course of performing the Contract, have any reason to believe that it will be unable to meet any completion date in accordance with the Design Schedule, it shall immediately notify Owner's Representative in writing. In such notice, Design/Builder shall state the reason for the delay including the party responsible, if any, and the steps being taken to remedy or minimize the impact of the delay. Failure of Design/Builder to submit such notice shall constitute a waiver by Design/Builder of any claim for an adjustment to the Contract Price, the Design Schedule, or the Contract Time. All extensions of time shall be governed by Articles 16 and 17 of this Agreement. Subject to the provisions of Section 13.7 of this Agreement, Owner shall review and approve, where appropriate, the Design Schedule, or any portion thereof.
Sample 1Sample 2See All (4)
Schedule of Design Services. Design/Builder shall, within ten (10) calendar days after execution of the Contract, submit for Owner's approval the Design Schedule for the performance of Design/Builder's Design Services, which shall include allowance for reasonable time required for the Director's review of submissions and for approvals of authorities having jurisdiction over the Project. This Schedule shall, upon approval by the Director, be considered incorporated and made a part of this Contract as Exhibit A. The Design Schedule, when approved by the Director, shall not, except for good cause, be exceeded by Design/Builder. Should Design/Builder at any time during the course of performing the Contract, have reason to believe that it will be unable to meet any completion date in accordance with the Design Schedule, it shall immediately notify the Director in writing. Design/Builder shall state the reason for the delay in the notice, including the party responsible, if any, and the steps being taken to remedy or minimize the impact of the delay. Failure of Design/Builder to submit such notice shall constitute a waiver by Design/Builder of any claim for an adjustment to the Contract Price, the Design Schedule, or the Contract Time. All extensions of time shall be governed by Articles 16 and 17 of this Contract. Subject to the provisions of Paragraph 13(G) of this Contract, Owner shall review and approve, where appropriate, the Design Schedule, or any portion thereof.
Sample 1
Schedule of Design Services. Design/Builder shall begin design immediately after execution of the Contract. The Design Schedule is expected to last 150 days, but in no case will extend beyond December 31, 2020. The Design Schedule shall not, except for good cause, be exceeded by Design/Builder. Preliminary Design Submittal 08/20/2020 Final Design Submittal 11/28/2020 Permits 09/29/2020 Should Design/Builder at any time during the course of performing the Contract, have reason to believe that it will be unable to meet any completion date in accordance with the Design Schedule, it shall immediately notify the Director in writing. Design/Builder shall state the reason for the delay in the notice, including the party responsible, if any, and the steps being taken to remedy or minimize the impact of the delay. Failure of Design/Builder to submit such notice shall constitute a waiver by Design/Builder of any claim for an adjustment to the Contract Price, the Design Schedule, or the Contract Time. All extensions of time shall be governed by Articles 16 and 17 of this Agreement. Subject to the provisions of Paragraph 13(G) of this Agreement, Owner shall review and approve, where appropriate, the Design Schedule, or any portion thereof.
Sample 1
Schedule of Design Services. Design-Builder shall, within ten (10) calendar days after award of the Contract and prior to City’s issuance of a written Notice to Proceed, submit for City's approval the baseline Design Schedule, addressing each stage of design shown in EXHIBIT I: DESIGN TASKS AND DELIVERABLES FOR VERTICAL PROJECTS attached hereto and incorporated herein by reference, for the performance of Design-Builder's Design Services, which shall include allowance for fifteen (15) calendar days for City’s review of submissions and for approvals of authorities having jurisdiction over the Project. This Schedule shall, upon approval by City, be considered incorporated and made a part of this Contract, attached hereto, incorporated herein by reference and labeled as EXHIBIT F: DESIGN-BUILDER’S DESIGN SCHEDULE AND DESIGN FEE SCHEDULE. The Design Schedule, when approved by City, shall not, except for good cause, be exceeded by Design-Builder. Should Design-Builder at any time during the course of performing the Contract, have reason to believe that it will be unable to meet any completion date in accordance with the Design Schedule, it immediately shall notify City in writing, stating the reason for the delay, the party responsible for the delay (if any) and the steps being taken to remedy or minimize the impact of the delay. Failure of Design-Builder to submit such notification shall constitute a waiver by Design- Builder of any claim Design-Builder may have for an adjustment to the Contract Price, the Design Schedule or the Contract Time. All extensions of time shall be governed by ARTICLE VIII of City’s General Conditions for Design/Build Contracts. Subject to the provisions of ARTICLE VIII.2 of said General Conditions, City shall review and approve, where appropriate, the Design Schedule or any portion thereof.
Sample 1
Schedule of Design Services. As a supplement to and consistent with the project schedule attached hereto and referenced in Paragraph 1.2, and to the extent not already a part of said project schedule, Design/Builder shall submit for Owner’s approval a design schedule for the performance of Design/Builder’s Design Services which shall include allowance for reasonable time required for Owner’s review of submissions and for approvals of authorities having jurisdiction over the Project, and which shall describe in detail the break-down of the portions of the Detailed Design specified by Design/Builder in completing the entire Detailed Design, and the dates by which those specified portions of the Detailed Design will be completed. The design schedule, when approved by Owner, shall not, except for good cause, be exceeded by Design/Builder. Should Design/Builder, at any time during the course of performing the Agreement, have any reason to believe that it will be unable to meet any completion date in
Sample 1

Related to Schedule of Design Services

  • Release of Design Plan The Engineer (1) will not release any roadway design plan created or collected under this contract except to its subproviders as necessary to complete the contract; (2) shall include a provision in all subcontracts which acknowledges the State’s ownership of the design plan and prohibits its use for any use other than the project identified in this contract; and (3) is responsible for any improper use of the design plan by its employees, officers, or subproviders, including costs, damages, or other liability resulting from improper use. Neither the Engineer nor any subprovider may charge a fee for the portion of the design plan created by the State.

  • Certificate of Designation The Certificate of Designation shall have been duly filed with the Secretary of State of the State of Delaware.

  • Effect of Designation (i) If notice designating an Early Termination Date is given under Section 6(a) or (b), the Early Termination Date will occur on the date so designated, whether or not the relevant Event of Default or Termination Event is then continuing. (ii) Upon the occurrence or effective designation of an Early Termination Date, no further payments or deliveries under Section 2(a)(i) or 2(e) in respect of the Terminated Transactions will be required to be made, but without prejudice to the other provisions of this Agreement. The amount, if any, payable in respect of an Early Termination Date shall be determined pursuant to Section 6(e).

  • SCHEDULE OF WORK FIRST PARTY’S proposed schedule for the various services required will be set forth in Exhibit A-1. In addition to services described in Section A1, the parties may from time to time agree in writing that FIRST PARTY, for additional compensation, shall perform additional services including but not limited to: • Change in the services because of changes in scope of the work. • Additional tasks not specified herein as required by the CITY. The CITY and FIRST PARTY shall agree in writing to any changes in compensation and/or changes in FIRST PARTY’s services before the commencement of any work. If FIRST PARTY deems work he/she has been directed to perform is beyond the scope of this agreement and constitutes extra work, FIRST PARTY shall immediately inform the CITY in writing of the fact. The CITY shall make a determination as to whether such work is in fact beyond the scope of this agreement and constitutes extra work. In the event that the CITY determines that such work does constitute extra work, it shall provide compensation to the FIRST PARTY in accordance with an agreed cost that is fair and equitable. This cost will be mutually agreed upon by the CITY and FIRST PARTY. A supplemental agreement providing for such compensation for extra work shall be negotiated between the CITY and the FIRST PARTY. Such

  • Certificate of Designations The Certificate of Designations shall have been filed with the Secretary of State of the State of Delaware.

  • If Designated If the HSP is Designated it will: (a) apply the principles of Active Offer in the provision of services; (b) continue to provide services to the public in French in accordance with the provisions of the FLSA; (c) maintain its French language services capacity; (d) submit a French language implementation report to the Funder on the date specified by the Funder, and thereafter, on each anniversary of that date, or on such other dates as the Funder may, by Notice, require; and (e) collect and submit to the Funder as requested by the Funder from time to time, French language services data.

  • Accuracy of Descriptions The statements made in the Registration Statement, the General Disclosure Package and the Prospectus (including in each case, the documents incorporated by reference therein) under the captions “Description of Capital Shares” and “Certain Provisions of New York Law and Our Certificate of Incorporation,” insofar as they purport to constitute a summary of the terms of the Company’s common shares, under the caption “Description of the Notes,” insofar as it purports to constitute a summary of the terms of the Securities, and under the captions “Prospectus Supplement Summary— Company Overview; -- Distribution Policy; - Restrictions Relating to Our Common Shares; - Emerging Growth Company Status and The Offering,” “Risk Factors,” “Dividends and Distribution Policy,” “Description of Common Shares,” “Certain Provisions of New York Law and our Certificate of Incorporation and Bylaws,” and “Certain U.S. Federal Income Tax Considerations” insofar as such statements constitute summaries of the terms of statutes, rules or regulations, legal matters or governmental proceedings or agreements, contracts and other documents, are accurate and fair summaries of the terms of such statutes, rules or regulations, legal matters or governmental proceedings or agreements, contracts and other documents in all material respects. All agreements between the Company or any of its Subsidiaries and any other party expressly referenced in the Registration Statement, the General Disclosure Package and the Prospectus are legal, valid and binding obligations of the Company or such Subsidiary, as applicable, enforceable against the Company or such Subsidiaries, as applicable, as appropriate, in accordance with their respective terms, except to the extent that enforceability may be limited by bankruptcy, insolvency, reorganization, fraudulent transfer, moratorium or similar laws affecting creditors’ rights generally and by general equitable principles and, with respect to equitable relief, the discretion of the court before which any proceeding therefor may be brought (regardless of whether enforcement is sought in a proceeding at law or in equity) and, with respect to any indemnification provisions contained therein, except as rights under those provisions may be limited by applicable law or policies underlying such law. The Company’s operating policies, investment guidelines and other policies described in the Registration Statement, General Disclosure Package and Prospectus accurately reflect in all material respects the current intentions of the Company with respect to the operation of its business, and no material deviation from such guidelines or policies is currently contemplated.

  • Accuracy of Descriptions and Exhibits The information in the Pre-Pricing Prospectus and the Prospectus under the captions “Risk Factors—Tax Risks,” “Cash Distribution Policy and Restrictions on Distributions,” “Provisions of Our Partnership Agreement Relating to Cash Distributions,” “Business—Regulation of Operations,” “Business—Regulation of Environmental and Occupational Safety and Health Matters,” “Business—Legal Proceedings,” “Management,” “Certain Relationships and Related Party Transactions,” “Conflicts of Interest and Duties,” “Description of Our Common Units,” “Our Partnership Agreement” and “Material Federal Income Tax Consequences,” and the information in the Registration Statement under Items 14 and 15 of Part II, in each case to the extent that it constitutes summaries of statutes, rules or regulations, summaries of legal or governmental proceedings, summaries of provisions of the Amended and Restated Partnership Agreement, or summaries of the terms of the contracts and other documents described and filed, is correct in all material respects; and there are no franchises, contracts, indentures, mortgages, deeds of trust, loan or credit agreements, bonds, notes, debentures, evidences of indebtedness, leases or other instruments, agreements or documents that are required, under the 1933 Act and the 1933 Act Regulations, (i) to be described in the Registration Statement, the General Disclosure Package or the Prospectus or (ii) to be filed as exhibits to the Registration Statement, which have not been so described or filed as required under the 1933 Act and the 1933 Act Regulations. To the CONE Entities’ knowledge, no other party to any such contract or other document has any intention not to render full performance as contemplated by the terms thereof.

  • ATTACHMENT A Equity Funds

  • SERVICE LEVEL DESCRIPTION The Fund Accounting Agreement is hereby amended by deleting the Service Level Description attached thereto and replacing it in its entirety with the Service Level Description attached hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!