CUSTOMER REMEDIES 5.1. If the Supplier (a) fails to deliver the Goods and/or the Goods do not comply with any of the undertakings or warranties set out in clause 2 and/or (b) fails to deliver and/or perform the Services in accordance with any of the warranties or undertakings contained in clause 4 and/or by the applicable date(s), the Customer shall, without limiting or affecting other rights or remedies available to it, have one or more of the following rights to:
5.1.1. terminate the Agreement with immediate effect by giving written notice to the Supplier;
5.1.2. reject the Goods (in whole or in part) whether or not title has passed and to return them to the Supplier at the Supplier’s own risk and expense;
5.1.3. require the Supplier to repair or replace the rejected Goods, or to provide a full refund of the price of the rejected Goods;
5.1.4. require Supplier to re-perform, rectify or replace the affected Services and/or Deliverables;
5.1.5. refuse to accept any subsequent performance of the Services and/or delivery of the Goods which the Supplier attempts to make;
5.1.6. recover from the Supplier any costs incurred by the Customer in obtaining substitute goods and/or services from a third party;
5.1.7. require a refund from the Supplier of sums paid in advance for Services that the Supplier has not provided and/or Goods that it has not delivered; and
5.1.8. claim damages for any additional costs, loss or expenses incurred by the Customer which are in any way attributable to the Supplier’s breach.
5.2. Notwithstanding any other rights or remedies available to Customer if the Goods are not delivered by the applicable date, the Customer may, at its option, claim or deduct 3% of the price of the Goods for each week’s delay in delivery, up to a maximum of 15% of the total price of the Goods. In the event such delay continues for six (6) weeks or more, Customer may terminate the Agreement with immediate effect upon given Supplier written notice.
5.3. These Terms shall extend to any substituted or remedial services and/or repaired or replacement goods supplied by the Supplier.
5.4. The Customer’s rights under the Agreement are in addition to its rights and remedies implied by statute and common law.
Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.
General Remedies Upon the occurrence of an Event of Default and during the continuation thereof, the Administrative Agent and the holders of the Secured Obligations shall have, in addition to the rights and remedies provided herein, in the Loan Documents, in any other documents relating to the Secured Obligations, or by law (including, without limitation, levy of attachment and garnishment), the rights and remedies of a secured party under the UCC of the jurisdiction applicable to the affected Collateral and, further, the Administrative Agent may, with or without judicial process or the aid and assistance of others (to the extent permitted under applicable law), (i) subject to the rights of tenants in possession, enter on any premises on which any of the Collateral may be located and, without resistance or interference by the Grantors, take possession of the Collateral, (ii) dispose of any Collateral on any such premises, (iii) require the Grantors to assemble and make available to the Administrative Agent at the expense of the Grantors any Collateral at any place and time designated by the Administrative Agent that is reasonably convenient to both parties, (iv) remove any Collateral from any such premises for the purpose of effecting sale or other disposition thereof, and/or (v) except as provided below in the case of notice required by law, without demand and without advertisement, notice or hearing, all of which each of the Grantors hereby waives to the fullest extent permitted by law, at any place and time or times, sell and deliver any or all Collateral held by or for it at public or private sale, by one or more contracts, in one or more parcels, for cash, upon credit or otherwise, at such prices and upon such terms as the Administrative Agent deems advisable, in its sole discretion (subject to any and all mandatory legal requirements). Each of the Grantors acknowledges that any private sale referenced above may be at prices and on terms less favorable to the seller than the prices and terms that might have been obtained at a public sale and agrees (to the extent permitted by applicable law) that such private sale shall be deemed to have been made in a commercially reasonable manner. Neither the Administrative Agent’s compliance with applicable law nor its disclaimer of warranties relating to the Collateral shall be considered to adversely affect the commercial reasonableness of any sale. In addition to all other sums due the Administrative Agent and the holders of the Secured Obligations with respect to the Secured Obligations, the Grantors shall pay the Administrative Agent and each of the holders of the Secured Obligations all reasonable documented costs and expenses actually incurred by the Administrative Agent or any such holder of the Secured Obligations, including, but not limited to, reasonable attorneys’ fees and court costs, in obtaining or liquidating the Collateral, in enforcing payment of the Secured Obligations, or in the prosecution or defense of any action or proceeding by or against the Administrative Agent or the holders of the Secured Obligations or the Grantors concerning any matter arising out of or connected with this Security Agreement, any Collateral or the Secured Obligations, including, without limitation, any of the foregoing arising in, arising under or related to a case under the Bankruptcy Code. To the extent the rights of notice cannot be legally waived hereunder, each Grantor agrees that any requirement of reasonable notice shall be met if such notice is personally served on or mailed, postage prepaid, to the Borrower in accordance with the notice provisions of Section 11.02 of the Credit Agreement at least ten Business Days before the time of sale or other event giving rise to the requirement of such notice. The Administrative Agent and the holders of the Secured Obligations shall not be obligated to make any sale or other disposition of the Collateral regardless of notice having been given. To the extent permitted by applicable law, any holder of the Secured Obligations may be a purchaser at any such sale. To the extent permitted by applicable law, each of the Grantors hereby waives all of its rights of redemption with respect to any such sale. Subject to the provisions of applicable law, the Administrative Agent and the holders of the Secured Obligations may postpone or cause the postponement of the sale of all or any portion of the Collateral by announcement at the time and place of such sale, and such sale may, without further notice, to the extent permitted by applicable law, be made at the time and place to which the sale was postponed, or the Administrative Agent and the holders of the Secured Obligations may further postpone such sale by announcement made at such time and place.
Special Remedies In view of the irreparable harm and damage which would undoubtedly occur to XStream as a result of a breach by the Employee of the covenants or agreements contained in this Article Four, and in view of the lack of an adequate remedy at law to protect XStream's interests, the Employee hereby covenants and agrees that XStream shall have the following additional rights and remedies in the event of a breach hereof:
(a) In addition to and not in limitation of any other rights, remedies or damages available to XStream, whether at law or in equity, it shall be entitled to a permanent injunction in order to prevent or to restrain any such breach by the Employee, or by the Employee's partners, agents, representatives, servants, employers, employees, affiliates and/or any and all persons directly or indirectly acting for or with him and the Employee hereby consents to the issuance of such a permanent injunction; and
(b) Because it is impossible to ascertain or estimate the entire or exact cost, damage or injury which XStream may sustain prior to the effective enforcement of such injunction, the Employee hereby covenants and agrees to pay over to XStream, in the event the employee violates the covenants and agreements contained in Section 4.2 hereof, the greater of:
(1) Any payment or compensation of any kind received by the Employee or by persons affiliated with or acting for or with the Employee, because of such violation before the issuance of such injunction, or
(2) The sum of Ten Thousand ($10,000.00) Dollars per violation, which sum shall be liquidated damages, and not a penalty, for the injuries suffered by XStream as a result of such violation, the Parties hereto agreeing that such liquidated damages are not intended as the exclusive remedy available to XStream for any breach of the covenants and agreements contained in this Article Four, prior to the issuance of such injunction, the Parties recognizing that the only adequate remedy to protect XStream from the injury caused by such breaches would be injunctive relief.
City’s Remedies In addition to any other remedies the City may have upon Developer and/or Developer’s contractor for the failure to provide and maintain insurance or policy endorsements to the extent and within the time required, the City shall have the right, to order Developer to stop work, and/or withhold any payment(s), which become due until Developer and/or Developer’s contractor demonstrates compliance with the requirements.
Specific Remedies (a) During any period other than a Cash Dominion Trigger Period and subject to the terms of the Credit Agreement, the Administrative Agent hereby authorizes each Grantor to collect such Grantor’s Accounts in the Ordinary Course of Business.
(b) During a Cash Dominion Trigger Period:
(i) upon the request of the Administrative Agent, each Grantor shall notify (such notice to be in form and substance satisfactory to the Administrative Agent) its Account Debtors and parties to the Material Contracts subject to a Security Interest that such Accounts and the Material Contracts have been assigned to the Administrative Agent, for the ratable benefit of the Secured Parties;
(ii) upon the request of the Administrative Agent, each Grantor shall forward to the Administrative Agent, on the last Business Day of each week, deposit slips related to all cash, money, checks or any other similar items of payment received by the Grantor during such week, and copies of such checks or any other similar items of payment, together with a statement showing the application of all payments on the Collateral during such week and a collection report with regard thereto, in form and substance satisfactory to the Administrative Agent;
(iii) the Administrative Agent may deliver such notices and instructions in accordance with control agreements covering Deposit Accounts (other than Excluded Accounts) and/or Securities Accounts. In addition, whenever any Grantor shall receive any cash, money, checks or any other similar items of payment relating to any Collateral (including any Proceeds of any Collateral), subject to the terms of any Permitted Liens, such Grantor agrees that it will, within one (1) Business Day of such receipt, deposit all such items of payment into the Dominion Account, and until such Grantor shall deposit such cash, money, checks or any other similar items of payment in the Dominion Account, such Grantor shall hold such cash, money, checks or any other similar items of payment in trust for the Secured Parties and as property of the Secured Parties, separate from the other funds of such Grantor, and the Administrative Agent shall have the right to transfer or direct the transfer of the balance of each Deposit Account (other than an Excluded Deposit Account) to the Dominion Account. All such Collateral and Proceeds of Collateral received by the Administrative Agent hereunder shall be held by the Administrative Agent in the Dominion Account as collateral security for all the Secured Obligations and shall not constitute payment thereof until applied as provided in Section 5.4;
(c) After the occurrence and during the continuance of an Event of Default:
(i) the Administrative Agent shall have the right to receive any and all cash dividends, payments or distributions made in respect of any Investment Property, any Partnership/LLC Interests or any other Proceeds paid in respect of any Investment Property or any Partnership/LLC Interests, and any or all of any Investment Property that is included as Collateral or any Partnership/LLC Interests that are Pledged Capital Stock may, at the option of the Administrative Agent and the Secured Parties, be registered in the name of the Administrative Agent or its nominee, and the Administrative Agent or its nominee may thereafter exercise (A) all voting, corporate and other rights pertaining to such Investment Property, or such Partnership/LLC Interests at any meeting of shareholders, partners or members of the relevant Issuers or otherwise and (B) any and all rights of conversion, exchange and subscription and any other rights, privileges or options pertaining to such Investment Property or such Partnership/LLC Interests as if it were the absolute owner thereof (including, without limitation, the right to exchange at its discretion any and all Investment Property or any and all Partnership/LLC Interests issued upon the merger, consolidation, reorganization, recapitalization or other fundamental change in the corporate, partnership or limited liability company structure of any Issuer that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary or upon the exercise by any Grantor or the Administrative Agent of any right, privilege or option pertaining to such Investment Property or such Partnership/LLC Interests, and in connection therewith, the right to deposit and deliver any and all of such Investment Property or any and all of such Partnership/LLC Interests with any committee, depositary, transfer agent, registrar or other designated agency upon such terms and conditions as the Administrative Agent may determine), all without liability except to account for property actually received by it; but the Administrative Agent shall have no duty to any Grantor to exercise any such right, privilege or option and the Administrative Agent and the other Secured Parties shall not be responsible for any failure to do so or delay in so doing. In furtherance thereof, each Grantor hereby authorizes and instructs each Issuer (i) that is a Grantor (other than Imation) or a Pledged Foreign Subsidiary with respect to any Collateral consisting of Investment Property and Partnership/LLC Interests of such Issuer to comply with any instruction received by it from the Administrative Agent in writing that (A) states that an Event of Default has occurred and is continuing and (B) is otherwise in accordance with the terms of this Agreement, without any other or further instructions from such Grantor, and each Grantor agrees that each Issuer shall be fully protected in so complying following receipt of such notice and prior to notice that such Event of Default is no longer continuing, and (ii) except as otherwise expressly permitted hereby and solely during a Cash Dominion Trigger Period, to pay any cash dividends, distributions or other payments with respect to any Investment Property, or Partnership/LLC Interests issued by such Issuer directly to the Dominion Account or such other Controlled Depositary as the Administrative Agent may direct; and
(ii) the Administrative Agent shall be entitled to (but shall not be required to): (A) proceed to perform any and all obligations of the applicable Grantor under any Material Contract and exercise all rights of such Grantor thereunder as fully as such Grantor itself could, (B) do all other acts which the Administrative Agent may deem necessary or proper to protect its Security Interest granted hereunder, provided such acts are not inconsistent with or in violation of the terms of any of the Credit Agreement, of the other Loan Documents or applicable Law, and (C) sell, assign or otherwise transfer any Material Contract in accordance with the Credit Agreement, the other Loan Documents and applicable Law, subject, however, to the prior approval of each other party to such Material Contract, to the extent required under the Material Contract.
(iii) The Administrative Agent is hereby granted an irrevocable, non-exclusive license or other right to use, license or sub-license (without payment of royalty or other compensation to any Person) of any or all Intellectual Property of each Grantor, computer hardware and software, trade secrets, brochures, customer lists, promotional and advertising materials, labels, packaging materials and other Property, in advertising for sale, marketing, selling, collecting, completing manufacture of, or otherwise exercising any rights or remedies with respect to, any Collateral; provided that the Administrative Agent shall not be entitled to exercise its rights under any such license, sub-license or right to use until such time as the Administrative Agent shall have received consent or direction from the Required Lenders pursuant to Section 8.02(d) of the Credit Agreement.
(d) Unless an Event of Default shall have occurred and be continuing and the Administrative Agent shall have given notice to the relevant Grantor of the Administrative Agent’s intent to exercise its corresponding rights pursuant to Section 5.2(b), each Grantor shall be permitted to receive all cash dividends, payments or other distributions made in respect of any Investment Property and any Partnership/LLC Interests, in each case paid in the Ordinary Course of Business to the extent permitted in the Credit Agreement, and to exercise all voting and other corporate, company and partnership rights with respect to any Investment Property and Partnership/LLC Interests; provided that, no vote shall be cast or other corporate, company and partnership right exercised or other action taken which, in the Administrative Agent’s reasonable judgment, would impair the Collateral in any material respect or which would result in a Default or Event of Default under any provision of the Credit Agreement, this Agreement or any other Loan Document.
Additional Remedies Upon the occurrence and during the continuation of an Event of Default, Secured Party shall have the right and power to:
(a) instruct Grantor, at its own expense, to notify any parties obligated on any of the Collateral, including any Account Grantors, to make payment directly to Secured Party of any amounts due or to become due thereunder, or Secured Party may directly notify such obligors of the security interest of Secured Party, and/or of the assignment to Secured Party of the Collateral and direct such obligors to make payment to Secured Party of any amounts due or to become due with respect thereto, and thereafter, collect any such amounts due on the Collateral directly from such Persons obligated thereon;
(b) enforce collection of any of the Collateral, including any Accounts, by suit or otherwise, or make any compromise or settlement with respect to any of the Collateral, or surrender, release or exchange all or any part thereof, or compromise, extend or renew for any period (whether or not longer than the original period) any indebtedness thereunder;
(c) take possession or control of any proceeds and products of any of the Collateral, including the proceeds of insurance thereon;
(d) extend, renew or modify for one or more periods (whether or not longer than the original period) the Obligations or any obligation of any nature of any other obligor with respect to the Obligations;
(e) grant releases, compromises or indulgences with respect to the Obligations, any extension or renewal of any of the Obligations, any security therefor, or to any other obligor with respect to the Obligations;
(f) transfer the whole or any part of Capital Securities which may constitute Collateral into the name of Secured Party or Secured Party's nominee without disclosing, if Secured Party so desires, that such Capital Securities so transferred are subject to the security interest of Secured Party, and any corporation, association, or any of the managers or trustees of any trust issuing any of such Capital Securities, or any transfer agent, shall not be bound to inquire, in the event that Secured Party or such nominee makes any further transfer of such Capital Securities, or any portion thereof, as to whether Secured Party or such nominee has the right to make such further transfer, and shall not be liable for transferring the same;
(g) vote the Collateral;
(h) make an election with respect to the Collateral under Section 1111 of the Bankruptcy Code or take action under Section 364 or any other section of Bankruptcy Code; provided, however, that any such action of Secured Party as set forth herein shall not, in any manner whatsoever, impair or affect the liability of Grantor hereunder, nor prejudice, waive, nor be construed to impair, affect, prejudice or waive Secured Party's rights and remedies at law, in equity or by statute, nor release, discharge, nor be construed to release or discharge, Grantor, any guarantor or other Person liable to Secured Party for the Obligations; and
(i) at any time, and from time to time, accept additions to, releases, reductions, exchanges or substitution of the Collateral, without in any way altering, impairing, diminishing or affecting the provisions of this Security Agreement, the Loan Documents, or any of the other Obligations, or Secured Party's rights hereunder, under the Obligations. Grantor hereby ratifies and confirms whatever Secured Party may do with respect to the Collateral and agrees that Secured Party shall not be liable for any error of judgment or mistakes of fact or law with respect to actions taken in connection with the Collateral other than as a result of intentional misconduct or gross negligence.
Provisional Remedies Although the procedures specified in this Article are the exclusive procedures for resolution of disputes arising out of or relating to this Agreement, either party may seek a preliminary injunction or other provisional equitable relief if, in its reasonable judgment, that action is necessary to avoid irreparable harm to itself or to preserve its rights under this Agreement.
Termination Remedies (a) If all conditions precedent to the obligations of Buyer set forth in Article VII, or of Seller set forth in Article VIII, (such Party that has satisfied its conditions precedent, the “Performing Party”) have been met and the transactions contemplated by this Agreement are not consummated on or before the Closing Date because of the failure of Buyer or Seller to perform any of its material obligations hereunder or the breach of any representation herein by Buyer or Seller (such party that has not satisfied its conditions precedent, the “Breaching Party”) and the Performing Party has performed all of its material obligations hereunder and has not breached any representation herein, then in such event, the Performing Party shall have the option to terminate this Agreement, in which case (i) if Buyer is the Breaching Party, Seller shall retain the Deposit as liquidated damages on account of Buyer’s failure to perform its obligations under this Agreement or Buyer’s breach of any representation under this Agreement, which remedy shall be the sole and exclusive remedy available to Seller for Buyer’s breaches or (ii) if Seller is the Breaching Party, then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after receipt of Buyer’s notice of termination. Buyer and Seller acknowledge and agree that (i) the Seller’s actual damages upon the event of such a termination are difficult to ascertain with any certainty, (ii) that the Deposit is a reasonable estimate of such actual damages and (iii) such liquidated damages do not constitute a penalty. Additionally, if Seller is the Breaching Party, in lieu of terminating this Agreement, Buyer shall have the right of specific performance of this Agreement.
(b) If this Agreement is terminated for any reason, other than as set forth in Section 11.03(a), then Seller shall return the Deposit to Buyer in immediately available funds within three (3) calendar days after the event giving rise to such payment to Buyer. Buyer and Seller shall thereupon have the rights and obligations set forth elsewhere herein.
Company’s Remedies Upon 30 days’ written notice to Authority, Company may terminate this Agreement and all of its obligations hereunder, if Company is not in default of any term, provision, or covenant of this Agreement or in the payment of any Rents, fees or other charges to Authority, and only upon or after the occurrence of any of the following events: the inability of Company to use Airport for a period of longer than 90 consecutive days due to war, terrorism, or the issuance of any order, rule or regulation by a competent governmental authority or court having jurisdiction over Authority, preventing Company from operating its business for a period of 90 consecutive days, provided, however, that such inability or such order, rule or regulation is not due to any fault or negligence of Company.
