Basic Services Fee 6.1.1 For Basic Services, as described in Article 1, and including all disciplines identified in Paragraph 15.1 as part of Basic Services, Architect/Engineer’s fee shall be a negotiated Basic Services Fee to cover all costs and profit.
6.1.2 The Architect/Engineer’s Basic Services Fee will be based on the Amount Available for the Construction Contract identified in the Program of Requirements.
6.1.3 In multiple package projects, the Basic Services Fee for each package shall be determined in a manner agreed to by A/E and Owner. The Architect/Engineer’s total Basic Services Fee will be the sum of the basic services fees for all packages.
6.1.4 If the description of the Architect/Engineer’s Basic Services is changed materially, the applicable fee shall be adjusted equitably.
Stormwater Notwithstanding any other provisions or terms of this Agreement, Company acknowledges that certain properties within the Premises or on Authority-owned land are subject to stormwater rules and regulations. Company agrees to observe and abide by such stormwater rules and regulations as may be applicable to the Premises, and, if applicable, Company hereby expressly covenants, warrants, and represents to Authority, in connection with Company’s operations on the Premises, the following:
A. Company is required to submit a Notice of Intent to use the State of Florida Multi-Sector Generic Permit for Stormwater Discharge Associated with Industrial Activity. Authority and Company both acknowledge that close cooperation is necessary to ensure compliance with any stormwater discharge permit terms and conditions, as well as to ensure safety and to minimize the cost of compliance. Company acknowledges further that it may be necessary to undertake actions to minimize the exposure of stormwater to “significant materials” (as such term may be defined by applicable stormwater rules and regulations) generated, stored, handled, or otherwise used by Company by implementing and maintaining “best management practices” (BMPs) (as such term may be defined in applicable stormwater rules and regulations). Company will establish a BMP plan for the Premises and submit a copy to Authority.
B. Company will be knowledgeable of any stormwater discharge permit requirements applicable to Company and with which Company will be obligated to comply. The submittal of a Notice of Intent will be made by Company to the FDEP, and a copy will be submitted to Authority. Company is required to comply with the following requirements including, but not limited to, certification of non-stormwater discharges; collection of stormwater samples; preparation of a Stormwater Pollution Prevention Plan or similar plans; implementation of BMPs; and maintenance and submittal of necessary records. In complying with such requirements, Company will observe applicable deadlines set by the regulatory agency that has jurisdiction over the permit. Company agrees to undertake, at its sole expense, those stormwater permit requirements for which it has received written notice from the regulatory agency and that apply to the Premises, and Company agrees that it will hold harmless and indemnify Authority for any violations or non-compliance with any such permit requirements.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Services Fee 5.1 The Transmission Services performed by TSO to Network User under this Standard Transmission Agreement are subject to the applicable Services fee calculated in accordance with attachment A of the Access Code for Transmission. In the event of any modification to the Regulated Tariffs, the Total Monthly Fee(s) and the Total Monthly Self-billing Fee(s) provided for in this Article 5.1 shall be adapted as from the calendar day of the entering into force of the modifications.
Stormwater Management a) The Owner AGREES to implement the requirements incorporated in the Draft Plan Conditions attached as Schedule “F” and any reports submitted to Kawartha Region Conservation Authority and the City pertaining to:
i) pre and post development run-off flows and water balance calculations, and the intended means of conveying stormwater flow from each Lot, Block and the entire proposed Plan of Subdivision;
ii) the anticipated impact of the Plan of Subdivision on water quality and phosphorus control, as it relates to fish and fish habitat once adequate protective measures have been taken;
iii) the means whereby erosion and sedimentation and their effects will be minimized on the site during and after construction;
iv) the site soil conditions, including grain size distribution profiles;
v) a site grading plan.
b) The Owner AGREES to erect and maintain all stormwater management and erosion and sedimentation control structures operating and in good repair during the construction period, in a manner satisfactory to Kawartha Region Conservation Authority and the City.
c) Prior to the execution of this Agreement, the Owner AGREES to confirm to the City that Conservation Authority has reviewed and approved the stormwater management report and plan, erosion and sedimentation plan, and final Lot Grading Plans as required under this Section.
a) UPGRADES TO EXISTING STORM SEWER
b) UPGRADES TO EXISTING SANITARY SEWER
Monitoring Services IDT staff shall, using methods that include face-to-face and other contacts with the member, monitor the services a member receives. This monitoring shall ensure that:
a. The member receives the services and supports authorized, arranged for and coordinated by the IDT staff;
b. The services and supports identified in the MCP as being provided by natural and community supports are being provided; and
c. The quality of the services and supports received is adequate and still necessary to continue to meet the needs and preferences of the member and support the member’s outcomes identified in the MCP.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
