Supplementary Conditions That part of the Contract Documents which amends or supplements these General Conditions.
Delivery Conditions (a) The Delivery Conditions are as follows:
(i) At Seller’s expense, Seller shall have secured all Governmental and grid operations approvals as are necessary for the safe and lawful operation and maintenance of the Project and to enable Seller to deliver Distribution Services at the Initial Contract Capacity to Buyer.
(ii) Seller shall have posted collateral as required by Section 10.4(a)(ii).
(iii) Seller shall have submitted for Buyer’s review a Project Safety Plan incorporating the elements described in Appendix XII, which must demonstrate Seller’s ability to comply with the Safety Requirements on the IDD and for the Delivery Term.
(iv) Seller shall have delivered to Buyer the Safety Attestation in accordance with Section 2(a) of Appendix XIV.
(v) As of the IDD, no Seller’s Event of Default shall have occurred and remain uncured.
(vi) At Seller’s expense, Seller or Contractor shall have constructed or caused to be constructed the Project as of the IDD and submitted the Certification for Commercial Operation in Appendix VII-A to enable (A) Seller to satisfy the obligations of the Seller herein and (B) the Project to deliver Distribution Services at the Contract Capacity to Buyer.
(vii) At Seller’s expense, Seller shall have installed any necessary metering to deliver the applicable Distribution Services in accordance with Section 4.1 and any applicable tariffs of the Utility Distribution Company.
(viii) Seller shall have met each Critical Milestone set forth in Appendix VI pursuant to Section 2.3.
Delivery Condition Subtenant acknowledges that it takes possession of the Subleased Premises in its “as is” condition, and further acknowledges that Sublandlord has made no representations or warranties of any kind or nature, whether express or implied, with respect to the Subleased Premises, the remainder of the Premises, the common areas, or the Building, nor has Sublandlord agreed to undertake or perform any modifications, alterations, or improvements to the Subleased Premises, the remainder of the Premises, the common areas or the Building which would inure to Subtenant’s benefit.
Unsafe Conditions In accordance with 29 CFR § 1977, occasions might arise when an employee is confronted with a choice between not performing assigned tasks or subjecting himself/herself to serious injury or death arising from a hazardous condition at the workplace. If the employee, with no reasonable alternative, refuses in good faith to expose himself/herself to the dangerous condition, he/she would be protected against subsequent discrimination. The condition causing the employee's apprehension of death or injury must be of such a nature that a reasonable person, under the circumstances then confronting the employee, would conclude that there is a real danger of death or serious injury and that there is insufficient time, due to the urgency of the situation, to eliminate the danger by resorting to regular statutory enforcement channels. In addition, in such circumstances, the employee, where possible, must also have sought from his Employer, and been unable to obtain, a correction of the dangerous condition.
Emergency Conditions “Emergency Condition” shall mean a condition or situation: (1) that in the judgment of the Party making the claim is imminently likely to endanger life or property; or (2) that, in the case of the Transmission Provider, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to the Transmission System, the Transmission Owner’s Interconnection Facilities or the Transmission Systems of others to which the Transmission System is directly connected; or (3) that, in the case of the Interconnection Customer, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to, the Small Generating Facility or the Interconnection Customer’s Interconnection Facilities. Under Emergency Conditions, the Transmission Owner may immediately suspend interconnection service and temporarily disconnect the Small Generating Facility. The Transmission Provider shall notify the Interconnection Customer promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Interconnection Customer’s operation of the Small Generating Facility. The Interconnection Customer shall notify the Transmission Provider promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Transmission Owner’s Transmission System or other Affected Systems. To the extent information is known, the notification shall describe the Emergency Condition, the extent of the damage or deficiency, the expected effect on the operation of both Parties’ facilities and operations, its anticipated duration, and the necessary corrective action.
Safe Conditions Whenever an employee reports a condition which the employee feels represents a violation of safety or health rules and regulations or which is an unreasonable hazard to persons or property, such conditions shall be promptly investigated. The appropriate administrator shall reply to the concern, in writing, if the employee's concern is communicated in writing.
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of:
(a) A member of a safety committee; or
(b) A person designated by a safety committee; or
(c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
Termination Conditions Such license shall not be terminated or its exploitation enjoined, until and unless: (i) Hitachi has committed a material breach of its obligations under this IP License Agreement, Opto-Device has given written notice of such breach to Hitachi and such breach remains uncured after the Cure Period, or, in the case of a breach, which cannot be cured within such Cure Period, Hitachi has not instituted within such Cure Period steps necessary to remedy the default and/or thereafter has not diligently pursued the same to completion; or (ii) such a material breach is incurable. In the event the breach is a curable breach that cannot be cured within the Cure Period but with respect to which Hitachi has instituted steps necessary to remedy the default and is thereafter diligently pursuing such cure, both parties shall negotiate to determine whether further pursuit of such cure is reasonable. If the parties cannot agree on a resolution in such negotiations, then this issue shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to decide whether such breach can be cured or any other alternative remedy should be adopted. In the event the breach is an incurable breach, the parties agree that the matter shall be referred to arbitration pursuant to the arbitration procedures set forth in Exhibit B hereto to determine the appropriate remedy. In the event that either party submits the dispute to arbitration, both parties shall cooperate in such binding arbitration in accordance with Exhibit B.
FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract.
19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days.
19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.
Buyer’s Conditions Buyer’s obligations to Close are conditioned upon the following (“Buyer’s Conditions”):
(i) All representations and warranties of Seller in this Agreement shall be true, correct and complete in all material respects as of the Closing Date and Seller shall have performed in all material respects all covenants and obligations required to be performed by Seller on or before the Closing Date.
(ii) Title Insurance Company is irrevocably committed to issue to Buyer an owner’s title insurance policy covering the Property with standard coverage customary in the state where the Property is located showing liability in the amount of the Purchase Price and showing insurable title to the Property vested in Buyer, subject only to the following: (a) Title Insurance Company’s standard exceptions; (b) liens for all current general and special real property taxes and assessments not yet due and payable; (c) liens of supplemental taxes, if any assessed; (d) any facts an accurate survey and/or a personal inspection of the Property may disclose; (e) the mortgage/deed of trust/deed to secure debt lien in connection with any Buyer financing; (f) any laws, regulations, ordinances (including but not limited to, zoning, building and environmental) as to the use, occupancy, subdivision or improvement of the Property adopted or imposed by any governmental body, or the effect of any non-compliance with or any violation thereof, including but not limited to, any disclosure and/or report required by ordinance; (g) rights of existing tenants and/or occupants of the Property (if any);
(h) covenants, restrictions, easements and other matters that do not materially impair the value of the Property or the use thereof; (i) non-monetary encumbrances disclosed to Buyer in writing prior to entering into this Agreement; and (j) any other matter for which Title Insurance Company agrees to provide insurance at no additional cost to Buyer.
