Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
SUB-CONTRACTING 31.1. The Authority approves the appointment of the sub-contractors specified in Schedule 10 (Approved Sub-contractors) in respect of the obligations specified in that Schedule.
31.2. The Contractor may not sub-contract its obligations under the Framework Agreement to other sub-contractors without the prior written consent of the Authority. Sub-contracting of any part of the Framework Agreement shall not relieve the Contractor of any obligation or duty attributable to the Contractor under the Framework Agreement. The Contractor shall be responsible for the acts and omissions of its sub-contractors as though they are its own.
31.3. Where the Contractor enters into a sub-contract the Contractor must ensure that a provision is included which:
31.3.1. requires payment to be made of all sums due by the Contractor to the sub- contractor within a specified period not exceeding 30 days from the receipt of a valid invoice as defined by the sub-contract requirements and provides that, where the Authority has made payment to the Contractor in respect of Services and the sub-contractor’s invoice relates to such Services then, to that extent, the invoice must be treated as valid and, provided the Contractor is not exercising a right of retention or set-off in respect of a breach of contract by the sub-contractor or in respect of a sum otherwise due by the sub-contractor to the Contractor, payment must be made to the sub-contractor without deduction;
31.3.2. notifies the sub-contractor that the sub-contract forms part of a larger contract for the benefit of the Authority and that should the sub-contractor have any difficulty in securing the timely payment of an invoice, that matter may be referred by the sub- contractor to the Authority;
31.3.3. requires that all contracts with subcontractors and suppliers which the subcontractor intends to procure, and which the subcontractor has not before the date of this Framework Agreement, already planned to award to a particular supplier are advertised through the Public Contracts Scotland procurement portal (xxx.xxxxxxxxxxxxxxxxxxxxxxx.xxx.xx) and awarded following a fair, open, transparent and competitive process proportionate to the nature and value of the contract; and
31.3.4. is in the same terms as that set out in this clause 31.3 (including for the avoidance of doubt this clause 31.3.4) subject only to modification to refer to the correct designation of the equivalent party as the Contractor and sub-contractor as the case may be.
31.4. The Contractor shall include in every sub-contract:
31.4.1 a right for the Contractor to terminate that sub-contract if the relevant sub- contractor fails to comply in the performance of its contract with legal obligations in the fields of environmental, social or employment law or if any of the termination events (involving substantial modification of the Contract, contract award despite the existence of exclusion grounds or a serious infringement of EU legal obligations) specified in clause 42.4 occur; and
31.4.2 a requirement that the sub-contractor includes a provision having the same effect as 31.4.1 in any sub-contract which it awards. In this Clause 31.4, ‘sub-contract’ means any contract between two or more contractors, at any stage of remoteness from the Authority in a sub-contracting chain, made wholly or substantially for the purpose of performing (or contributing to the performanace of) the whole or any part of this Framework Agreement.
31.5. Where requested by the Authority, copies of any sub-contract must be sent by the Contractor to the Authority as soon as reasonably practicable.
31.6. Where the Contractor proposes to enter into a sub-contract it must:
31.6.1 advertise its intention to do so in at least one trade journal, and the Public Contracts Scotland Portal; and
31.6.2 follow a procedure leading to the selection of the sub-contractor which ensures reasonable competition following principles of equal treatment, non-discrimination and transparency and which ensures that such procedure is accessible by small and medium enterprises.
Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
Contract Amendment A. Contract Exhibit A, Scope of Work, is hereby deleted and replaced in its entirety with the attached Exhibit A, Scope of Work, which is incorporated into the Contract by reference herein.
B. Contract Exhibit B, Additional Special Contract Conditions, is hereby deleted in its entirety and replaced with the attached Exhibit B, Additional Special Contract Conditions, which is incorporated into the ACS by reference herein.
C. Contract Exhibit I, PUR 1355: Foreign Country of Concern Attestation, is hereby incorporated in its entirety to the ACS by reference herein.
Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.
Sub-processing 11.1 The data importer shall not subcontract any of its processing operations performed on behalf of the data exporter under the Clauses without the prior written consent of the data exporter. Where the data importer subcontracts its obligations under the Clauses, with the consent of the data exporter, it shall do so only by way of a written agreement with the sub-processor which imposes the same obligations on the sub- processor as are imposed on the data importer under the Clauses. Where the sub-processor fails to fulfil its data protection obligations under such written agreement the data importer shall remain fully liable to the data exporter for the performance of the sub-processor’s obligations under such agreement.
11.2 The prior written contract between the data importer and the sub-processor shall also provide for a third-party beneficiary clause as laid down in Clause 3 for cases where the data subject is not able to bring the claim for compensation referred to in paragraph 1 of Clause 6 against the data exporter or the data importer because they have factually disappeared or have ceased to exist in law or have become insolvent and no successor entity has assumed the entire legal obligations of the data exporter or data importer by contract or by operation of law. Such third-party liability of the sub-processor shall be limited to its own processing operations under the Clauses.
11.3 The provisions relating to data protection aspects for sub-processing of the contract referred to in paragraph 1 shall be governed by the law of the Member State in which the data exporter is established, namely ........................................
11.4 The data exporter shall keep a list of sub-processing agreements concluded under the Clauses and notified by the data importer pursuant to Clause 5(j), which shall be updated at least once a year. The list shall be available to the data exporter’s data protection supervisory authority.
Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.
