Variation in Estimated Quantities Sample Clauses

Variation in Estimated Quantities. If the quantity of a unit-price item is an estimated quantity and the actual quantity of the unit-price item varies more than fifteen percent (15%) above or below the estimated quantity, an equitable adjustment in the Contract Price shall be made upon demand of either Party. The equitable adjustment shall be made upon any increase or decrease in costs due solely to the variation above one hundred fifteen percent (115%) or below eighty-five percent (85%) of the estimated quantity.
Sample 1Sample 2
AutoNDA by SimpleDocs
Variation in Estimated Quantities. 36.1 If the quantity of a unit-priced item in this CONTRACT is an estimated quantity and the actual quantity of the unit-priced item varies more than 25 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 125 percent or below 75 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the CONTRACTOR may request, in writing, an extension of time, to be received by the OWNER within 10 days from the beginning of the delay, or within such further period as may be granted by the OWNER before the date of final settlement of the CONTRACT. Upon the receipt of a written request for an extension, the OWNER shall ascertain the facts and make any appropriate adjustment for extending the completion date.
Sample 1Sample 2
Variation in Estimated Quantities. If unit prices are stated in the Contract Documents or subsequently agreed upon, and if the quantities originally contemplated as so changed in a proposed Change Order, that application or the agreed unit prices to the quantities of Work proposed will cause substantial inequity to the County or the Contractor, the applicable unit prices shall be equitably adjusted.
Sample 1Sample 2
Variation in Estimated Quantities. Payment to the Contractor will be made only for the actual quantities of work performed and accepted in conformance with the contract. When the accepted quantity of work performed under a unit item varies from the original proposal quantity, payment will be at the unit contract price for all work unless the total accepted quantity of any contract item, adjusted to exclude added or deleted amounts included in change orders accepted by both parties, increases or decreases by more than 25 percent from the original proposal quantity. In that case, payment for contract work may be adjusted as described herein: The adjusted final quantity shall be determined by starting with the final accepted quantity measured after all work under an item has been completed. From this amount, subtract any quantities included in additive change orders accepted by both parties. Then, to the resulting amount, add any quantities included in deductive change orders accepted by both parties. The final result of this calculation shall become the adjusted final quantity and the basis for comparison to the original proposal quantity.
Sample 1

Related to Variation in Estimated Quantities

  • ESTIMATED QUANTITIES 1.1 The quantities set forth in the line items and specification document are approximate and represent the estimated requirements for the contract period. 1.2 Items listed may or may not be an inclusive requirements for this category. 1.3 Category items not listed, but distributed by bidder are to be referred to as kindred items. Kindred items shall receive the same percentage of discount or pricing structure as items listed in the specification document. 1.4 The unit prices and the extended total prices shall be used as a basis for the evaluation of bids. The actual quantity of materials necessary may be more or less than the estimates listed in the specification document, but the City/County shall be neither obligated nor limited to any specified amount. If possible, the Owners will restrict increases/decreases to 20% of the estimated quantities listed in the specification document.

  • VARIATION IN QUANTITY The state assumes no liability for commodities produced, processed or shipped in excess of the amount specified herein.

  • ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.

  • Statement of Estimated Direct Expenses In addition, Landlord shall give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated Tenant’s Share of Direct Expenses (the “Estimated Direct Expenses”). The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Estimated Direct Expenses under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Direct Expenses theretofore delivered to the extent necessary. Thereafter, Tenant shall pay, with its next installment of Base Rent due that is at least thirty (30) days thereafter, a fraction of the Estimated Direct Expenses for the then-current Expense Year (reduced by any amounts paid pursuant to the last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year, including the month of such payment, and twelve (12) as its denominator. Until a new Estimate Statement is furnished (which Landlord shall have the right to deliver to Tenant at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Direct Expenses set forth in the previous Estimate Statement delivered by Landlord to Tenant.

  • Estimated Cost Estimated costs by construction phases for Specified Roads listed in A7 are stated by segments in the Schedule of Items. Such estimated costs are subject to adjustment under B3.3, B5.2, B5.21, B5.212, B5.25, and B5.26. Appropriately adjusted costs shall be made a part of a revised Schedule of Items and shown as adjustments to Timber Sale Account. The revised Schedule of Items shall supersede any prior Schedule of Items when it is dated and signed by Contracting Officer and a copy is furnished to Purchaser.

  • Cost Estimates If this Agreement pertains to the design of a public works project, CONSULTANT shall submit estimates of probable construction costs at each phase of design submittal. If the total estimated construction cost at any submittal exceeds ten percent (10%) of CITY’s stated construction budget, CONSULTANT shall make recommendations to CITY for aligning the PROJECT design with the budget, incorporate CITY approved recommendations, and revise the design to meet the Project budget, at no additional cost to CITY.

  • Cost Estimate The cost estimate shall set out the estimated costs for the proposed Change Order in such a way that a fair evaluation can be made. It shall include a breakdown for labor, materials, equipment and markups for overhead and profit, unless TxDOT agrees otherwise. If the work is to be performed by Subcontractors and if the work is sufficiently defined to obtain Subcontractor quotes, DB Contractor shall obtain quotes (with breakdowns showing cost of labor, materials, equipment and markups for overhead and profit) on the Subcontractor’s stationery and shall include such quotes as back-up for DB Contractor’s estimate. No markup shall be allowed in excess of the amounts allowed under Section 10.6. DB Contractor shall identify all conditions with respect to prices or other aspects of the cost estimate, such as pricing contingent on firm orders being made by a certain date or the occurrence or non-occurrence of an event.

  • Estimated Costs The proposed GMP Change Order shall include separately identified dollar amounts, stated as fixed sums, for Actual Costs as estimated by the Design-Builder for the complete construction of the Project, which amount shall include the all Trade Contract and Subcontract Sums, costs of materials, and any Component Change Order Sums;

  • USE OF ESTIMATES The Sponsor is authorized to make all Net Asset Value determinations (including, without limitation, for purposes of determining redemption payments and calculating Sponsor’s Fees) on the basis of estimated numbers. The Sponsor shall not (unless the Sponsor otherwise determines) attempt to make any retroactive adjustments in order to reflect the differences between such estimated and the final numbers, but rather shall reflect such differences in the Accounting Period in which final numbers become available. The Sponsor also shall not (unless the Sponsor otherwise determines) revise Sponsor’s Fee calculations to reflect differences between estimated and final numbers (including differences which have resulted in economic benefit to a Sponsor Party). If, after payment of redemption proceeds, the Sponsor determines that adjustment to the Net Asset Value of the redeemed Units is necessary, the redeeming Investor (if the Net Asset Value is adjusted upwards) or the remaining Investors (if the Net Asset Value is adjusted downwards) will bear the risk of such adjustment. The redeeming Investor will neither receive further distributions from, nor will it be required to reimburse, this FuturesAccess Fund in such circumstances.

  • Estimated Closing Statement (i) No later than three (3) Business Days prior to the Closing Date, the Company shall deliver to Acquiror (A) a statement (the “Estimated Closing Statement”) setting forth the Company’s good faith estimates of (1) the Estimated Net Working Capital (as well as the resulting Estimated Net Working Capital Surplus (if any) or Estimated Net Working Capital Shortfall (if any)), (2) the Estimated Transaction Expenses, (3) the Estimated Closing Cash and (4) the Estimated Closing Debt, and (B) a schedule which shall include (1) the Estimated Total Stock Purchase Consideration, (2) wire instructions for the payments to be made to NewCo at the Closing pursuant to Section 2.3(b), (3) each Seller’s Pro Rata Percentage and the portion of the Estimated Total Stock Purchase Consideration attributable to each Seller; and (4) wire instructions for the payments of Debt, and the Estimated Transaction Expenses, including, for the avoidance of doubt, the Transaction Bonuses, to be made to the applicable payees thereof pursuant to Section 2.3(b) (such schedule delivered pursuant to this clause (B), the “Payment Schedule”). The Estimated Closing Statement shall be prepared by the Company in accordance with the Agreed Principles. (ii) The Company shall consider in good faith any reasonable comments or objections to any amounts set forth on the Estimated Closing Statement notified to it by Acquiror prior to the Closing and if, prior to the Closing, the Company and Acquiror agree to make any modification to the Estimated Closing Statement, then the Estimated Closing Statement as so modified shall be deemed to be the Estimated Closing Statement; provided, that the failure of the Company and Acquiror to reach such mutual agreement will not give any party the right to terminate this Agreement or otherwise delay or fail to close the Stock Purchase or the other transactions contemplated hereunder. (iii) Acquiror shall be entitled to rely on the accuracy of the Estimated Closing Statement and the Payment Schedule in all respects in making any payments pursuant to this Agreement, and all obligations to make such payments shall be deemed fulfilled to the extent such payments are made in accordance with this Agreement, the Payment Schedule, and the Estimated Closing Statement, including the Earn-Out Payment. None of Acquiror or any of its Affiliates (including, after the Closing, the Company) or the Seller Representative shall have any liability or obligation to any Person, including the Sellers and the Seller Guarantors, for any Damages arising from or relating to any errors, omissions or inaccuracies in the calculations of the portion of any amounts payable to any Seller or any other Person or any other errors, omissions or inaccuracy in the information set forth on the Estimated Closing Statement or the Payment Schedule.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!