Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Wage Adjustments If the funding available to be used for wages provided by Government in any fiscal year increases, the Employer shall pass on such increases to employees consistent with the funding increase adjusted for any additional deficits that this contract incurs. This will be the case whether the funding increase is for the entire year or simply a portion of it, and wage increases shall be effective upon the effective date of the increased funding. Should there be no increase provided by Government, wages will be maintained at their present levels. Should there be a decrease in funding, then the Employer will maintain wages at present levels. The Employer will promptly provide the Union with any information it receives from the Government regarding funding available for wages, and the parties will meet as required to work towards cooperative resolution of any issues arising from this Government information.
Adjustments for Stock Splits, Etc Wherever in this Agreement there is a reference to a specific number of shares of Common Stock or Preferred Stock of the Company of any class or series, then, upon the occurrence of any subdivision, combination or stock dividend of such class or series of stock, the specific number of shares so referenced in this Agreement shall automatically be proportionally adjusted to reflect the affect on the outstanding shares of such class or series of stock by such subdivision, combination or stock dividend.
Adjustments for Combinations, Etc If the outstanding Shares are combined or consolidated, by reclassification or otherwise, into a lesser number of shares, the Warrant Price shall be proportionately increased.
Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.
Adjustments for Stock Splits The parties acknowledge and agree that all share-related numbers contained in this Agreement shall be adjusted to take into account any stock split, stock dividend or similar event effected with respect to the Placement Shares.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Share Adjustments If the Company's outstanding shares of Common Stock are increased or decreased or changed into or exchanged for a different number or kind of shares or other securities of the Company by reason of any recapitalization, reclassification, stock split, combination of shares, stock dividend, or transaction having similar effect, the Board shall proportionately and appropriately adjust the number and kind of shares that are subject to this Option and the Exercise Price Per Share, without any change in the aggregate price to be paid therefor upon exercise of this Option.
Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--
(i) In the contract price or delivery schedule or both; and
(ii) In such other provisions of the contract as may be affected.
(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Adjustments for Stock Splits and Combinations If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date) effect a split of the outstanding Common Stock, the applicable Conversion Price in effect immediately prior to the stock split shall be proportionately decreased. If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date), combine the outstanding shares of Common Stock, the applicable Conversion Price in effect immediately prior to the combination shall be proportionately increased. Any adjustments under this Section 3.4(a)(i) shall be effective at the close of business on the date the stock split or combination occurs.
