Working Drawings and Specifications Sample Clauses

Working Drawings and Specifications. 1. Immediately following the date on which Store Design Drawings bearing Landlord’s approval are returned to Tenant, Tenant shall engage an Architect registered in the state in which the Shopping Center is located for the purpose of preparing Working Drawings and Specifications for Tenant’s Leased Premises. Working Drawings and Specifications shall be prepared in strict compliance with the Design Criteria and requirements as set forth in Section IV of this Exhibit and shall adhere to the Store Design Drawings as approved by Landlord. 2. All Working Drawings and Specifications prepared by Xxxxxx’s Architect shall be submitted by Tenant, in the form of one (l) set of reproducible prints (i.e., sepias) and one (l) set of prints, to Landlord within twenty-one (21) days from receipt by Tenant of Landlord’s approved Store Design Drawings. Any required revisions to such Working Drawings and Specifications shall be prepared and resubmitted by Tenant to Landlord within ten (10) days of receipt of notice from Landlord. 3. Tenant shall pay all fees of its Architect. The fee identified in Section II of Exhibit B-1 shall, in part, be for Landlord’s review of the various plans and specifications submitted by Tenant and for Landlord’s facilitation and coordination of Tenant’s actual construction in the Leased Premises; however, Landlord shall not be in any way responsible or liable with respect to the accuracy, sufficiency, or feasibility of Tenant’s plans, and Tenant shall be totally responsible for same.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Working Drawings and Specifications. Working Drawings and Specifications as set forth in Section V of this Exhibit.
Sample 1Sample 2Sample 3See All (5)
Working Drawings and Specifications. After Landlord receives Tenant’s space plan, Landlord will provide Tenant with the Final Plans. Tenant will approve or disapprove the Final Plans in writing within five Business Days after receiving the same. Tenant will not withhold its approval except for reasonable cause and will not act in an arbitrary or capricious manner in connection with approving the Final Plans. If Tenant fails to notify Landlord of Tenant’s approval or disapproval of the Final Plans within the five Business Day period described in this section, such failure is deemed to be a Tenant Delay. If Tenant disapproves the Final Plans within the five Business Day period described in this section, Landlord will revise the Final Plans and submit the same to Tenant for approval. Tenant will have the same approval rights and approval time period with respect to the revised Final Plans as Tenant had with respect to the initial Final Plans as described in this section. Tenant acknowledges, however, that if Tenant’s failure to timely approve the Final Plans constitutes a Tenant Delay, then the Delivery Date is automatically extended day for day for each day of delay after the date by which Tenant was obligated to approve the Final Plans. Landlord will seal as required by the Laws the Final Plans after Tenant approves the same and will submit the same for permits and construction bids. Tenant will not order long lead time items that will delay Substantial Completion of the Tenant’s Improvements. Landlord will exercise commercially reasonable efforts to notify Tenant if Tenant orders long lead time items that will delay Substantial Completion of the Tenant’s Improvements.
Sample 1
Working Drawings and Specifications. Within thirty (30) days after receipt of Tenant's space plan, Landlord will provide Tenant with proposed Final Plans. Within ten (10) Business Days after receipt from Landlord of proposed Final Plans, Tenant will approve, disapprove or make suggested revisions to Landlord with regard to the Final Plans. If Tenant disapproves or makes suggested revisions to the Final Plans, Landlord will revise the Final Plans and submit copies to the Tenant for approval within ten (10) Business Days after Landlord's receipt of Tenant's initial response to Landlord's proposed plans. Tenant acknowledges, however, that if Tenant has not approved the Final Plans on or before February 29, 2000, then such delay, unless attributable to Landlord, is a Tenant Delay and the Delivery Date is automatically extended day for day for each day of delay after February 29, 2000. The parties shall exercise their best efforts to finalize the Final Plans on or before February 29, 2000. Agreed upon Final Plans shall be sealed and submitted for permit and construction bids. Notwithstanding the foregoing, final plans for the 6th Floor, at Tenant's sole cost and expense, may be revised up to six (6) months prior to the 6th Floor Commencement Date.
Sample 1
Working Drawings and Specifications. Landlord will exercise commercially reasonable efforts to notify Tenant if Tenant orders long lead time items that will delay Substantial Completion of Tenant’s Improvements. Landlord will use commercially reasonable efforts to order materials within reasonable time to minimize such delays.
Sample 1
Working Drawings and Specifications. For the preparation of working drawings and specifications, Owner will pay Architect, against monthly bxxxxxxx, according to Schedule A which is attached hereto and incorporated herein, a fixed fee for complete working drawings and specifications not to exceed $69,625.00. Notwithstanding anything to the contrary contained herein, the final payment of $10,000 of said $69,625.00 shall not be made by Owner (and shall not be accrue any interest or late fees) until all said drawings and specifications have been approved by all government officials and building permits issued for the construction of the New Facility.
Sample 1
Working Drawings and Specifications. Architect shall prepare contract documents commonly referred to as working drawings and specifications, setting forth in detail and prescribing the work to be done, and the materials, workmanship, and finishes required for each Project. This shall be an amplification of the preliminary drawings and outline specifications approved by District and shall be in such form as will enable District to: (1) secure any required
Sample 1
AutoNDA by SimpleDocs
Working Drawings and Specifications. In accordance with the Space Plan approved by Tenant and Landlord, Working Drawings and Specifications (including engineering services) required for construction permits and Completion of the Premises will be provided. Final Working Drawings and Specifications are to be approved by Tenant and Landlord in writing prior to commencing construction.
Sample 1
Working Drawings and Specifications 
Sample 1

Related to Working Drawings and Specifications

  • Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents. 9.2 Materials or Work described in words that so applied have a well-known technical or trade meaning shall be deemed to refer to recognized standards, unless noted otherwise. 9.3 Trade Name or Trade Term It is not the intention of the Contract Documents to go into detailed descriptions of any materials and/or methods commonly known to the trade under “trade name” or “trade term.” The mere mention or notation of “trade name” or “trade term” shall be considered a sufficient notice to Developer that it will be required to complete the work so named, complete, finished, and operable, with all its appurtenances, according to the best practices of the trade. 9.4 The naming of any material and/or equipment shall mean furnishing and installing of same, including all incidental and accessory items thereto and/or labor therefor, as per best practices of the trade(s) involved, unless specifically noted otherwise. 9.5 Contract Documents are complementary, and what is called for by one shall be binding as if called for by all. As such, Drawings and Specifications are intended to be fully cooperative and to agree. However, if Developer observes that Drawings and Specifications are in conflict with the Contract Documents, Developer shall promptly notify District and Architect in writing, and any necessary changes shall be made as provided in the Contract Documents. 9.6 Figured dimensions shall be followed in preference to scaled dimensions, and Developer shall make all additional measurements necessary for the work and shall be responsible for their accuracy. Before ordering any material or doing any work, each Developer shall verify all measurements at the building and shall be responsible for the correctness of same. 9.7 Should any question arise concerning the intent or meaning of the Contract Documents, including the Plans and Specifications, the question shall be submitted to the District for interpretation. If a conflict exists in the Contract Documents, these Construction Provisions shall control over the Facilities Lease, which shall control over the Site Lease, which shall control over Division 1 Documents, which shall control over Division 2 through Division 49 documents, which shall control over figured dimensions, which shall control over large-scale drawings, which shall control over small-scale drawings. In no case shall a document calling for lower quality and/or quantity of material or workmanship control. However, in the case of discrepancy or ambiguity solely between and among the Drawings and Specifications, the discrepancy or ambiguity shall be resolved in favor of the interpretation that will provide District with the functionally complete and operable Project described in the Drawings and Specifications. 9.8 Drawings and Specifications are intended to comply with all laws, ordinances, rules, and regulations of constituted authorities having jurisdiction, and where referred to in the Contract Documents, the laws, ordinances, rules, and regulations shall be considered as a part of the Contract Documents within the limits specified. 9.9 As required by Section 4-317(c), Part 1, Title 24, CCR: “Should any existing conditions such as deterioration or non-complying construction be discovered which is not covered by the DSA-approved documents wherein the finished work will not comply with Title 24, California Code of Regulations, a construction change document, or a separate set of plans and specifications, detailing and specifying the required repair work shall be submitted to and approved by DSA before proceeding with the repair work.”

  • Working Drawings Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).

  • Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.

  • Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.

  • Final Working Drawings Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Tenant shall cause the approved Final Space Plan to be converted by the Architect and the Engineers to complete architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such review and any disapproval of Landlord in connection therewith. Landlord and Tenant acknowledge that the Final Space Plans may not depict certain structural elements of the Building and/or various elements of the Building systems which may result in material modifications to the Final Working Drawings (“Space Plan Modifications”) Furthermore, the Final Space Plans for the construction of the Tenant Improvements may require modification to account for the requirements of building codes and other legal requirements of applicable governmental entities, including, but not limited to, Title 24 and the Americans with Disabilities Act (collectively the “Building Codes”). The Final Working Drawings shall materially conform to the Final Space Plans, taking into account (i) Space Plan Modifications, (ii) the requirements of the Building Codes, (iii) other modifications resulting from physical constraints of the Premises and (iv) modifications requested by Tenant and consented to by Landlord, which consent shall not be unreasonably withheld. Tenant agrees that, in addition to other factors and considerations Landlord may take into account, it shall not be unreasonable for Landlord to withhold its consent to any matters set forth in the Final Working Drawings and not contained in the Final Space Plans, (i) if such requested modifications would not comply with the Building Codes or any laws, (ii) subject to Section 7 if such requested modifications would cause the anticipated cost of the Tenant Improvements to exceed the Tenant Improvement Allowance (unless Tenant agrees to be responsible for all such costs, and provide evidence satisfactory to Landlord of Tenant’s ability to pay such amounts, including escrow the funds if required by Landlord), (iii) if such requested modifications would not increase the value of the Tenant Improvements, (iv) if such requested modifications would increase the burden on the Building systems, either during construction or after completion of same.

  • Technical Specifications and Drawings a) The Goods and Related Services supplied under this Contract shall conform to the technical specifications and standards mentioned in Section VI, Schedule of Requirements and, when no applicable standard is mentioned, the standard shall be equivalent or superior to the official standards whose application is appropriate to the Goods' country of origin. b) The Supplier shall be entitled to disclaim responsibility for any design, data, drawing, specification or other document, or any modification thereof provided or designed by or on behalf of the Procuring Entity, by giving a notice of such disclaimer to the Procuring Entity. c) Wherever references are made in the Contract to codes and standards in accordance with which it shall be executed, the edition or the revised version of such codes and standards shall be those specified in the Schedule of Requirements. During Contract execution, any changes in any such codes and standards shall be applied only after approval by the Procuring Entity and shall be treated in accordance with GCC Clause 33.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!