Agreed Milestone Completion Date definition

Agreed Milestone Completion Date means the date specified as such in the Project Specific Conditions and being the date by which the Milestones shall be achieved; “Agreed Project Completion means the date specified as such in the Project Specific Conditions and being the date
Sample 1Sample 2
Agreed Milestone Completion Date means the date specified as such in the Project Specific Conditions and being the date by which the Milestones shall be achieved; “Agreed Project Completion Date” means the date specified as such in the Project Specific Conditions and being the date that all of the Project Activities shall be finished and complete; “Agreement” means this Agreement including its Schedules and Annexes; “Application” means the application for grant funding from the Local Growth Fund (and any annexes thereto) for the Project that was submitted by the Grant Recipient to the LEP and is provided atSchedule 4 (The Application); “Change” means in relation to the Project as defined in the Application any of the following changes (in accordance with Clause 0 (Changes to the Project)):a change in the Ownership, Control and Nature of Business of the Grant Recipient;a change in the nature or purpose of the Project; any change to the Eligible Expenditure;any change to the Expenditure Profile;any change to any of the Key Milestone Dates; any change to any of the Project Outputs; andany material change to the Project Programme (that is, more
Sample 1

Related to Agreed Milestone Completion Date

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Development Milestone Event shall have the meaning set forth in Section 9.2(a).

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Milestone Event has the meaning set forth in Section 8.4.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Development Milestone Payment shall have the meaning set forth in Section 9.2(a).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: