Assignment or Subcontracting. The terms, covenants, and conditions contained herein shall apply to and bind the heirs, successors, executors, administrators and assigns of the parties. Furthermore, neither the performance of this Contract nor any portion thereof may be assigned or subcontracted by Contractor without the express written consent of County. Any attempt by Contractor to assign or sub-contract the performance or any portion thereof of this Contract without the express written consent of County shall be invalid and shall constitute a breach of this Contract.
Assignment or Subcontracting. Consultant shall not assign, sublet, or transfer this Agreement or any rights under or interest in this Agreement without the written consent of the District, which may be withheld for any reason. Any attempt to so assign or so transfer without such consent shall be void and without legal effect and shall constitute grounds for termination. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement. Nothing contained herein shall prevent Consultant from employing independent associates, and subconsultants as Consultant may deem appropriate to assist in the performance of services hereunder.
Assignment or Subcontracting. Neither party may assign, pledge, mortgage or otherwise encumber any of its rights under this Agreement without the prior consent of the other.
Assignment or Subcontracting. No assignment or subcontracting by Servicer of any part of this Agreement or of funds to be received under this Agreement shall be of any force or effect unless the assignment has had the prior written approval of Client. Client may terminate this Agreement rather than accept any proposed assignment or subcontracting. Such assignment or subcontracting may be approved by the Client’s manager or his designee.
Assignment or Subcontracting. The Contractor shall not assign or subcontract any portion of the services provided under the terms of this Agreement without obtaining prior written approval from the City; except that, from time to time the Contractor may subcontract with another qualified attorney from the approved list of attorneys attached as Exhibit A to assist with the services provided under the terms of this Agreement. Any request for an addition to the approved list of qualified attorneys shall be submitted to the City Administrator for approval prior to said attorney providing services under this Agreement, which approval may be withheld in the City’s sole discretion. If after three (3) business days, no decision is made by the City Administrator on a requested addition to the approved list set forth in Exhibit A, the addition shall be deemed accepted by the City. A qualified attorney shall mean an attorney licensed to practice law in the state of Washington who is able to certify that he or she complies with the applicable Standards for Indigent Defense Services as adopted by the Washington Supreme Court and as hereafter amended. All terms and conditions of this Agreement shall apply to any approved subcontract related to this Agreement. Contractor shall remain fully responsible for compliance with the terms and conditions of this Agreement on any case assigned to Contractor, including cases in which services are subcontracted by Contractor to another attorney as provided herein. The City shall not assign any defense of indigent defendants to any Contractor or Attorney at Law other than to the Contractor herein; except that, the City shall assign an indigent defendant with whom the Contractor has a conflict of interest, to an Attorney-at- Law of the City’s choice. Except as otherwise provided, assignment of indigent defendant cases to an Attorney-at-Law other than the Contractor shall constitute a material breach of this agreement by the City, and the City shall be liable to the Contractor for the fee that the Contractor would have received from the City had the case been properly assigned to the Contractor.
Assignment or Subcontracting. Except as provided in this Agreement, the Construction Manager must perform the CM Services required pursuant to this Agreement using staff and other resources available within its own organization, and no portion of the CM Services shall be performed by any subcontractor to the Construction Manager. The Construction Manager shall have no right or power to assign, sublet, transfer or otherwise substitute its interest in, or its rights and obligations pursuant to, this Agreement without the prior written consent of the District, which consent the District may withhold, delay, or condition in its sole discretion. Notwithstanding the foregoing, the District shall not unreasonably withhold, delay or condition its consent with respect to the subcontracting of any CM Services that require architect, structural engineer, or environmental consultant services that cannot be provided by a member of the Construction Manager’s staff.
Assignment or Subcontracting. No assignment or subcontracting of Buyer orders by Seller shall be made without the express written approval of Xxxxx. Payment to assignee of any claim under this Order shall be subject to set-off or recoupment for any present or future claim or claims which Buyer may have against Seller.
Assignment or Subcontracting. The terms, covenants, and conditions contained herein shall apply to and bind the heirs, successors, executors, administrators and assigns of the Parties. Furthermore, neither the performance of this Contract nor any portion thereof may be assigned or subcontracted by Contractor without the express written consent of County. Any attempt by Contractor to assign or subcontract the performance or any portion thereof of this Contract without the express written consent of County shall be invalid and shall constitute a breach of this Contract. Notwithstanding the foregoing, the County hereby authorizes Contractor to use the services of subcontractors with County written approval.
Assignment or Subcontracting. 8.1.1. The Contractor must not without the written consent of the Principal’s Representative subcontract the Works or assign the benefit of this Contract or any portion or allow a subcontractor to subcontract any part of the Works or assign any benefit of the subcontract.
8.1.2. Even if the Principal’s Representative has consented to a subcontracting of the Works or any portion:
a. the Principal’s Representative may prohibit any subcontractor from performing any portion of the Works and may remove any subcontractor from the Works; and
b. the Contractor shall remain fully responsible for the completion of the Works in accordance with this Contract.
8.1.3. Subject to a direction from the Principal’s Representative to the contrary, the Approved Subcontractors may be used by the Contractor in the execution of the Works.
8.1.4. The Contractor must ensure that all subcontractors comply with this Contract insofar as it specifies the manner of carrying out the Works.
Assignment or Subcontracting. 6.1 The Consultant shall not assign or subcontract it rights or obligations under this agreement or any specific right or obligation hereunder without the prior written consent of the Company.
6.2 This agreement shall not be assignable by the Company without the prior written consent of the Consultant except in the case of an assignment by the Company to a corporation, trust or other organization which is a successor to the Company by operation of law. Any such successor shall be bound hereunder and by the terms of said assignment in the same manner as the Company is bound hereunder. For greater certainty, it is acknowledged by all parties hereto that in the event the Company is amalgamated with or wound up into another corporation, this agreement shall remain in full force and effect.
