Construction Start Date Milestone definition

Construction Start Date Milestone. The date by which continuous construction of permanent structures shall begin at the Site in accordance with Attachment L (Reporting Milestones). For PV Facilities, the Construction Start Date occurs when Seller begins installation of the mounting and racking components.
Sample 1Sample 2Sample 3

Examples of Construction Start Date Milestone in a sentence

  • If Seller achieves Commercial Operation on or before the Milestone deadline as set forth in Section 4.3(b)(ii), as such deadline may be extended in accordance with Section 4.3(e), Buyer shall promptly refund all Daily LD Amounts previously received as a result of Seller’s failure to meet the Construction Start Date Milestone deadline as set forth in Section 4.3(b)(i).

  • If Seller achieves Commercial Operation on or before the Milestone deadline as set forth in Section 4.3(b)(ii), as such deadline may be extended in accordance with Section 4.3(e), Buyer shall promptly refund all Development Liquidated Damages previously received as a result of Seller’s failure to meet the Construction Start Date Milestone deadline as set forth in Section 4.3(b)(i).

Related to Construction Start Date Milestone

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Statement has the meaning set out in clause 6.1;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Guaranteed Construction Start Date means the Expected Construction Start Date, as such date may be extended by the Development Cure Period.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Benchmark Transition Start Date means, in the case of a Benchmark Transition Event, the earlier of (a) the applicable Benchmark Replacement Date and (b) if such Benchmark Transition Event is a public statement or publication of information of a prospective event, the 90th day prior to the expected date of such event as of such public statement or publication of information (or if the expected date of such prospective event is fewer than 90 days after such statement or publication, the date of such statement or publication).

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.