Final Completion Punch List definition

Final Completion Punch List is defined in the definition of "Commercial
Sample 1Sample 2Sample 3
Final Completion Punch List has the meaning set forth in Section 12.5.
Sample 1Sample 2Sample 3
Final Completion Punch List means, as of Commercial Operation, a list of all items to be completed in order to achieve Final Completion.
Sample 1

Examples of Final Completion Punch List in a sentence

  • If the Owner’s Representative determines that the Work is not Finally Complete, a Final Completion Punch List will be issued to CMR.

  • CMR may request a second inspection when CMR deems the Final Completion Punch List to have been completed.

  • Upon achievement of Final Completion for each Unit, Contractor shall submit to Owner an invoice for the final Milestone Payment for such Unit and other payments due under this Agreement (the "Final Payment Invoice") which shall set forth the remaining amounts due to Contractor pursuant to this Agreement (minus any amounts that are still being held for Final Completion Punch List items for such Unit that cannot be completed until the next Nuclear Fuel re-load, as provided in Section 12.5).

  • Prior to Substantial Completion of a Unit, the Parties shall jointly determine and agree upon a comprehensive list of remaining Work, which shall be of a minor nature and not prevent commercial operation of the Unit (the "Final Completion Punch List").

  • Owner shall have the right to withhold from the Milestone Payment due upon Substantial Completion of a Unit an amount of money equal to one hundred twenty-five percent (125%) of the expected cost of completion of the Final Completion Punch List, which amount shall be released to Contractor upon Final Completion of the Unit.

  • In lieu of the retention described in this Section 12.5, Contractor shall have the right to provide a letter of credit or a bond, in form and substance reasonably satisfactory to Owner, for the completion of the Final Completion Punch List, in which case the amount retained for the Final Completion Punch List shall be released to Contractor.


More Definitions of Final Completion Punch List

Final Completion Punch List means the list of minor items of Work to be completed or corrected by Contractor for Final Completion.
Sample 1
Final Completion Punch List is defined in Section 2.8. “Financing Documents” is defined in the Lender Consent. “Force Majeure” is defined in Section 14.1.
Sample 1
Final Completion Punch List means that upon the DBE achieving Substantial Completion, a list of remaining minor and/or trivial items which can include, without limitation, minor or trivial items in the Work, the delivery of spare parts, delivery of owner operation manuals, final clean up, etc. Upon reaching Substantial Completion, a Final Completion Punch List will be prepared and a value estimated for each item thereon which shall be communicated to all members of the Project Team. “Final Completion” and “Finally Complete” mean the point at which the following conditions have occurred with respect to the entire Work:
Sample 1
Final Completion Punch List means the list of minor and/or trivial items of Work that are defective and need to be completed and corrected by DBE to achieve Final Completion.
Sample 1

Related to Final Completion Punch List

  • Final Completion Date means the date on which Final Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Construction Completion Certificate means a document:

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Punch List Items means such items (i) as are reasonably necessary or appropriate to fully complete the construction, equipping and furnishing of the Hotel in accordance with this Contract and (ii) that, unless otherwise agreed by Buyer in its sole discretion, (a) individually and in the aggregate do not and will not prohibit, cause a delay in or otherwise adversely affect, under applicable Legal Requirements, the Franchise Agreement or otherwise, the opening of the Hotel for business to the public or the continued occupancy and operation of the Hotel as contemplated under the Brand and (b) may be corrected or completed, subject to delays caused by Force Majeure, within not more than sixty (60) days.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Subproject means a development activity proposed by a Beneficiary under Part A.2 (d) of the Project and financed or to be financed through a Subproject Grant (as hereinafter defined) made out of the proceeds of the Development Credit;

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.