Substantially Completed means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Substantially Complete “Substantially Completed” or “Substantial Completion” with regard to the Shell and Core Improvements shall mean the later to occur of (i) the substantial completion of construction of the Shell and Core Improvements, as certified by the Project Architect, pursuant to and evidenced by a fully executed AIA G704 form signed by Landlord, Non-TI Construction Manager and the Project Architect, with the exception of any Punch List Items (as defined below), and (ii) the issuance by the City of Cambridge of a certificate of occupancy for the Shell and Core (unless such certificate is not available due to requirements of the Tenant Improvements or improvements to other tenant spaces that in either case preclude issuance of a certificate of occupancy, in which case a certificate of occupancy shall not be a condition precedent to Substantial Completion, but Landlord shall obtain such a certificate within a reasonable time after such requirements have been satisfied). Punch List Items shall be diligently completed by Landlord within a reasonable time, provided that Punch List Items which arise due to a delayed delivery of such Punch List Item or material portion thereof shall be completed no later than ninety (90) days after Substantial Completion (except for items which cannot be completed until the Tenant Improvements are completed by Tenant, or for items affected by seasonal conditions, each of which shall be completed as soon as practicable). The term “Punch List Items” shall mean minor items of completion, correction or repair with respect to the Non-TI Project Improvements, which, by their nature, will not interfere with, or impair in any material respect, Tenant’s use or occupancy of the Project for the purposes contemplated under the Lease, and which will not delay Tenant’s commencement of business operations in the Premises. Following the Substantial Completion of the Shell and Core Improvements, Landlord shall use commercially reasonable efforts to complete any remaining Site Improvements that are not complete as of the date of Substantial Completion of the Shell and Core Improvements as soon as reasonably practicable, which for all seasonal components of the Site Improvements shall be prior to the end of the first full planting season that begins after the date of Substantial Completion of the Shell and Core Improvements.
Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Administratively complete means an application for a sand dune mining permit that is determined by the department to satisfy all of the conditions of this part and rules promulgated under this part.
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.
Final Completion Date means the date on which Final Completion occurs.
Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date
Landlord’s Work means the work of constructing the Tenant Improvements.
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
Needs Improvement the Educator’s performance on a standard or overall is below the requirements of a standard or overall, but is not considered to be unsatisfactory at this time. Improvement is necessary and expected. Unsatisfactory: the Educator’s performance on a standard or overall has not significantly improved following a rating of needs improvement, or the Educator’s performance is consistently below the requirements of a standard or overall and is considered inadequate, or both.
Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.
Not Typically Combined Network Elements shall mean that the particular Network Elements requested by ONS are not elements that BellSouth combines for its use in its network.