Project Construction Completion Date definition

Project Construction Completion Date means a date of the completion of the Construction Period, which shall be at the expiry of a period of 3 (Three) years from the Compliance Date or such
Sample 1Sample 2Sample 3
Project Construction Completion Date means a date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of Concessioning Authority) by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Project Construction Completion Certificate is issued by Concessioning Authority as per Article 2.8.
Sample 1Sample 2Sample 3
Project Construction Completion Date. – means 2 (two) months from the date of issue of compliance certificate.
Sample 1Sample 2

Examples of Project Construction Completion Date in a sentence

  • The Concessionaire shall adhere to the safe construction parameters and complete the construction works before the Project Construction Completion Date or such extended date as may be approved by Concessioning Authority.

  • The Concessionaire has failed to implement the Project in accordance with the provisions of the Agreement and such failure, in the reasonable estimation of Concessioning Authority, is likely to delay achieving Project Construction Completion Date.

  • The Concessionaire may be allowed to novate the agreement after completion of 10 (ten) consecutive years after Project Construction Completion Date subject to the condition that the novatee fulfills the minimum eligibility criteria.

  • The Project Construction Completion Date shall occur on the [ 1095th (one thousand and ninety fifth )] day from the Appointed Date.

  • The Concessionaire has failed to implement the Project in accordance with the provisions of this Agreement and such failure, in the reasonable estimation of Concessioning Authority, is likely to delay achieving Scheduled Project Construction Completion Date.

  • Upon Termination of this Agreement on account of Concessionaire Event of Default, prior to the Project Construction Completion Date, Concessioning Authority shall retain payments, if any, already received.

  • Within 90 (ninety) days of the Project Construction Completion Date, the Concessionaire shall furnish to the A u t h o r i t y and the Independent Engineer a complete set of as- built Drawings, in 5 (Five) hard copies and in micro film form or in such other medium as may be acceptable to the Authority, reflecting work as actually designed, engineered and constructed.

  • The Project Manager will have authority to order minor changes in the Project not involving an adjustment in the Project GMP or an extension of the Project Construction Completion Date and not inconsistent with the intent of the Plans and Specifications and other contract documents for the Project.

  • In addition, the Construction Performance Security shall be adjusted, as condition precedent to issuance of the Final Project Construction Completion Certificate, prior to the Project Construction Completion Date so that it is equal in value to [one percent (1%)]of the Total Project Cost less the aggregate of any encashments made by the GoS prior to the date of adjustment.

  • In the event that Project Construction Completion Date is not achieved prior to the expiry of 24 months for any reason other than Force Majeure or reasons attributable to the Concessioning Authority or any Competent Authority, the Concessionaire shall, subject to paragraph below, pay to the Concessioning Authority damages for delay beyond the date on which the construction completion was due to the extent of 0.1% of the Performance Security per day for every day of delay subject to maximum Rs.


More Definitions of Project Construction Completion Date

Project Construction Completion Date means the date of Final Completion of all of the Project Improvements Work in accordance with all of the requirements of this Agreement.
Sample 1
Project Construction Completion Date has the meaning set forth in Section 20(b).
Sample 1
Project Construction Completion Date means November 12, 1999."
Sample 1
Project Construction Completion Date means the date on which the Agent receives (a) a certificate from the Borrower certifying that each of the matters described on Schedule 1.1(b) and identified as to be certified by the Borrower are true and correct in all respects, and (b) a certificate of the Independent Engineer certifying that each of the matters described on Schedule 1.1(b) and identified as to be certified by the Independent Engineer are true and correct in all respects.
Sample 1
Project Construction Completion Date means the date on which the Project Construction Termination occurs.
Sample 1
Project Construction Completion Date set forth in Annex A to the Original Equipment Loan Agreement is hereby amended and restated in its entirety to read as follows:
Sample 1

Related to Project Construction Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Construction Work means any work in connection with⎯

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Zone shall have the meaning set forth in Clause 8.3 (i);